Client (Party A): Organizer (Party B): Project: After friendly negotiation, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by. Article 1: Project overview 1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ 3. Construction Content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details. 4. Entrusting method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ 2, labor costs _ _ _ _ _ _ _ yuan; 3. The design fee is _ _ _ _ _ _ yuan; 4, the construction freight _ _ _ _ _ _ yuan; 5. The handling fee is _ _ _ _ _ _ _ yuan; 6. The management fee is _ _ _ _ _ _ yuan; 7. Other expenses (specify content) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Article 3: Quality requirements 1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties. 2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state. 3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs. 4. All materials and equipment purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project. 5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection. Article 4: Material supply: 1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials. 2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. 3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping. Article 5: Payment method: 1. After the contract is signed, Party A shall pay 100% of the project cost and 50% of the project cost; When the progress of the construction period is over half (year, month and day), Party A will pay 40% of the project payment for the second time. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs). Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use. 2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing the construction change form and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot. 3. If Party A fails to pay the project price in advance within the time limit stipulated in this contract, Party A shall pay 1% of the unpaid project price to Party B for each overdue day. 4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B ... Article 6: The construction period is 1. If the construction period is delayed due to Party B's reasons, Party A shall pay 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price as lost time. 2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged. 3. During the construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction. 4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged. 5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent. Article 7: Project Acceptance 1. Project quality acceptance, except concealed works, after all the works are completed, Party B shall organize Party A to carry out the completion acceptance. Both parties shall handle the project settlement and handover procedures. 2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified. 3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses. Article 8: Other matters 1. Party A's responsibility 1) must provide the house floor plan and water, electricity and gas circuit diagram approved by the property management department, otherwise Party A will provide the house floor plan and water, electricity and gas circuit diagram and make disclosure to Party B on site ... 2) The second renovation project will empty the house in whole or in part, and remove obstacles that affect the construction. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B.. 3) If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood. 2. Responsibility of Party B 1) Party B shall take the initiative to show its business license, membership card or construction qualification; The handling salesman must have a certificate of entrustment from the legal representative. 2) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity. 3) Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible. 4) Strictly perform the contract and implement the credit period. If the completion is delayed, such as divestiture, slowdown or excuses to induce Party A to advance funds, it will be considered as a breach of contract after investigation. 5) Take the warranty responsibility within the scope of decoration construction. The warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. Article 9: After the contract for breach of contract comes into effect, during the performance of the contract, the party that cancels the contract without authorization shall pay 5% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated. Article 10: Dispute Resolution During the performance of this contract, in case of any dispute between the two parties, both parties shall settle it through consultation without affecting the progress of the project. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract. Article 11: Modification and Termination of the Contract 1. After this contract is signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures. 2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated. Article 12: Contract comes into effect 1. This contract and its annexes shall come into effect after being sealed by both parties. 2. The supplementary contract has the same legal effect as this contract. 3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy. Party a (owner): (signature) party b: (signature) address: enterprise address: postal code: work unit: legal representative: entrusted agent: entrusted agent: telephone: signing address: signing date: