Model equipment sales contract 1
Buyer: (hereinafter referred to as Party A)
Supplier: (hereinafter referred to as Party B)
In order to increase the sense of responsibility of Party A and Party B and ensure the realization of their respective economic goals, Party A and Party B, through friendly negotiation, have reached the following agreement on Party A's procurement from Party B:
I. Subject matter of the contract (name, specification, model, unit price, etc.). )
Second, the contract amount
Total contract amount: RMB 10,000 Yuan only: RMB 10,000 Yuan only.
Three. Time and method of payment
1. This contract shall be paid in three installments: within days after the contract comes into effect, Party A shall pay Party B% of the total contract amount; Party A shall pay% of the total contract price to Party B within one week after the equipment installation and debugging are completed and the preliminary acceptance is qualified. Party A shall pay% of the total contract price to Party B within one week after the normal operation of the equipment and formal acceptance by both parties; Pay off the balance after the warranty expires. (Change and modify according to the relevant provisions of the bidding documents)
2. Friendship link:
3. Party B shall issue a VAT invoice of the same amount to Party A the day before each contract payment (agreed upon according to the actual situation).
Four. Time, place and method of delivery
1. Delivery time: within days after the contract comes into effect.
2. Place of delivery: Name of consignee: (name of contractor) Address:
3. Delivery method: Party B is responsible for the transportation of goods.
4. Freight mode: automobile transportation.
5. The delivery date of the contract equipment is after Party B has transported it to Midea Industrial City, installed and debugged it, put it into use and passed the acceptance of Party A. (What is the delivery date and delivery according to the actual situation? If it is agreed that the supplier regards the installation, debugging and commissioning of the equipment as delivery, the time when the equipment passes the acceptance of Party A shall be clearly agreed. ) Party A picks up the goods at the delivery place agreed in the contract, and Party B shall bear the transportation fee and transportation insurance premium. The risk of damage or loss of contract equipment shall be transferred to Party A after Party B completes the delivery.
6. Party B shall inform Party A of the delivery situation (delivery time, number of pieces, etc.). ) Within one working day after the delivery of the contract equipment, Party A shall promptly pick up the contract equipment consigned by Party B after it reaches the place specified in the contract.
7. When Party A takes delivery, it shall check the packaging of the contract equipment in the outer box. The contract equipment can only be picked up if the outer box packaging is intact. If the outer box packaging of the contract equipment is damaged or the packaging quantity of the contract equipment is found to be inconsistent, Party B shall be informed within working days, so that Party B can handle the claim procedures for the contract equipment in distress.
8. Party A shall properly receive and keep the contract equipment delivered by Party B. Party A shall be responsible for properly keeping the goods sent by mistake or repeatedly, and notify Party B in time, and the expenses arising therefrom shall be borne by Party B. ..
9. If Party A requests to change the delivery place, it shall notify Party B fifteen days before the delivery date stipulated in the contract. The transportation expenses increased due to the change of delivery address shall be borne by Party A. ..
Verb (abbreviation of verb) Time, place, standard and method of acceptance.
1. Acceptance time: Party B shall complete the equipment installation and commissioning within the day after the contract comes into effect, and Party A shall arrange preliminary acceptance within the day after the installation and commissioning. Within days after the contract comes into effect, the equipment passes the acceptance of both parties, and Party A will issue an acceptance certificate.
2. Acceptance place:
3, acceptance criteria:
Intransitive verb door-to-door service (it is recommended to make an agreement according to the actual situation)
1. The on-site personnel of the supplier shall abide by the factory rules and regulations of the buyer, and Party B shall be responsible for any violation.
2. The supplier's field personnel should take care of themselves.
3. If the buyer needs to invite the supplier to provide technical services to deal with non-quality problems, the supplier shall provide assistance.
Seven. personnel training
Party B is responsible for the operation training, maintenance training and equipment maintenance training for Party A's operation and maintenance personnel and related technical personnel, so that they can fully master all the technologies used and enable Party A's personnel to use and maintain the equipment normally. (According to the technical requirements of the equipment, agreed according to the specific situation or stipulated in the technical agreement; If it is not necessary, it may not be agreed)
Eight. Warranty method
1. From the date of acceptance of the equipment by both parties, free warranty service shall be provided according to the terms specified by the manufacturer, and the free warranty service period shall be years. During the warranty period, Party B must send someone to Party A's site for maintenance within days after receiving Party A's warranty notice.
2. During the warranty period, if damage is caused by irresistible reasons such as fire, flood, earthquake, electromagnetic interference and man-made sabotage factors of Party A, Party B shall be responsible for free maintenance, and Party A shall bear the expenses of equipment and materials.
3. After the warranty period, Party B must send someone to Party A's site for maintenance within days after receiving Party A's maintenance notice. For the maintenance and replacement of equipment, Party A will charge the cost and service fee as appropriate, and the charging standard will be agreed separately.
Nine. responsibility for breach of contract
1. If Party A returns goods halfway without reason, it shall pay Party B a penalty of 5% of the total contract amount. This agreement can be made if the other party proposes similar terms, otherwise it is suggested to delete this paragraph. )
2. Party A shall pay Party B a penalty of 2‰ of the total contract amount for each overdue day, and the total accumulated penalty shall not exceed 5% of the total contract amount. (This agreement can be made if the other party proposes a similar clause, otherwise it is suggested to delete this clause. )
3. If the delivery is overdue, Party B shall pay 1% of the total contract price as liquidated damages for each day overdue, and the total amount of liquidated damages shall not exceed 30% of the total contract price. If the delivery is overdue for more than days, it shall be deemed as non-delivery. Party B shall double the payment made by Party A, and Party A shall have the right to terminate the contract and require Party B to pay 30% of the contract price as liquidated damages.
4. During the warranty period, if Party B fails to fulfill the warranty obligations within the time limit agreed in the contract, Party B shall pay Party A a penalty of 1% of the contract amount for each day overdue, and compensate Party A for other economic losses. The total fine shall not exceed 30% of the total contract amount. If Party B fails to fulfill the warranty obligations for more than 30 days, Party A has the right to terminate the contract and claim compensation for economic losses; If Party B fails to maintain the normal use of the equipment within 30 days after receiving the notice from Party A, Party A has the right to request Party B to exchange goods or terminate the contract, and claim compensation for economic losses. After the warranty period, if Party B fails to perform the maintenance obligations within the time limit agreed in the contract, Party B shall pay Party A a penalty of 1% of the contract amount for each day of delay, and compensate Party A for other economic losses, with the total penalty not exceeding 30% of the total contract amount.
5. If the equipment fails to pass the acceptance of Party A as agreed in the contract, Party A shall be paid a penalty of 1% of the total contract amount for each day of delay; If Party A still fails to pass the acceptance inspection after more than days, Party A has the right to terminate the contract, and Party B shall immediately return the money received and compensate Party A for other economic losses incurred as a result.
Force majeure
In the event of a force majeure event, the party affected by the force majeure event shall obtain the certificate issued by the notary office that the contract cannot be performed or fully performed, and notify the other party in time within 15 working days after the event. Both parties agree that they can be exempted from all or part of their responsibilities accordingly.
XI。 alteration of contract
Matters not covered in this contract shall be settled by both parties through consultation; Changes and amendments to the contract shall be made in writing after mutual consent.
Twelve. Dispute resolution method
Any dispute between the two parties shall be settled through consultation; If negotiation fails, either party shall bring a lawsuit to the people's court where Party A is located.
Thirteen. Entry into force and termination of contract
This contract shall come into effect after being signed and sealed by both parties, and shall be terminated after the rights and obligations of both parties are fulfilled.
14. This contract is made in quadruplicate, with each party holding two copies, all of which have the same legal effect.
Party A: Party B:
Representative: representative:
Date: Date:
Signing place:
Model equipment purchase and sale contract II
ContractNo.: _ _ _ _ _ _
Project name: _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _
Demander: _ _ _ _ _ _ _ Supplier: _ _ _ _ _ _ _
After full consultation, both parties agree to sign this contract according to the following terms:
I. Subject matter of the contract
1. 1 equipment name, specification (model) and configuration
Equipment brand name _ _ _ _ _ _ Equipment specification (model: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
1.2 All equipment provided by the supplier must meet the requirements of current relevant national standards, and should be brand-new, unused, technologically advanced, mature and reliable.
1.3 The configuration, technical indicators and performance of the equipment must meet the requirements of the current relevant national standards and specifications.
1.4 the seller shall provide technical guidance and technical cooperation related to the inspection, installation, debugging, acceptance, operation and maintenance of the contract equipment.
1.5 The supplier shall provide equipment transportation, handle transportation insurance and be responsible for unloading.
1.6 The supplier shall provide installation guidance and start-up debugging of the equipment. The warranty period of the equipment is 18 months from the date of shipment or 12 months from the date of commissioning, whichever comes first.
Second, the scope of supply
2. 1 is generated by _ _ _ _ _ _ _
(Name of equipment) _ _ _ _ _ _ _ _ and the supply, installation, commissioning and after-sales service of random spare parts.
2.2 The contract scope of supply includes all equipment, technical data and attached accessories in Item 2. 1. However, in the course of implementation, if any omissions and shortages are found, which are not included in the delivery list, but are indeed required within the supplier's scope of supply and necessary to meet the requirements of current relevant national standards and specifications, the supplier shall be responsible for supplementing the missing equipment, technical data, attached accessories, etc. , no charge.
Three. Currency of the contract price _ _ _ _ _ _ _ (RMB)
serial number
device name
Quantity: _ _ _ _ _ _ _
Comprehensive price
1, totaling RMB _ _ _ _ _ _ _ in words.
The price in the above table includes not only the contract equipment expenses (including the attached accessories) and the taxes, freight and miscellaneous fees, insurance fees and other expenses of the contract equipment, but also all the expenses related to this contract such as technical information, technical services, installation guidance, start-up debugging and technical guidance provided by the seller to the buyer.
Once the contract price is signed and takes effect by both parties, it will remain unchanged during the execution of the contract.
Four. pay
4. 1 The currency used in this contract is RMB.
4.2 Payment method: bank payment.
4.3 Payment of Equipment Payment
4.3. 1 equipment deposit: within seven days after the signing of the contract, the buyer shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
4.3.2 Payment for equipment: The buyer sends a delivery notice to the seller and pays the total contract amount of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Verb (abbreviation for verb) delivery and transportation
5. 1 transportation location _ _ _ _ _ _ _
5.2 Delivery place: The delivery place of the contract equipment is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
5.3 The Seller is responsible for transporting the contract equipment from the Seller's factory to the delivery place.
5.4 The Seller shall deliver all the equipment and accessories under this contract to the delivery place specified in this contract within _ _ _ _ _ days after receiving the down payment. If the buyer fails to pay on time according to the payment time agreed in 4.3, the delivery time of the supplier will be postponed in turn according to the number of days of delayed payment.
5.5 The actual delivery date of the contract equipment shall be based on the time of the product delivery acceptance form filled in by the seller and the buyer at the delivery place, which is the basis for calculating the liquidated damages for late delivery of the equipment in Article 10.4 of this contract.
Packaging and marking of intransitive verbs
6. 1 All the equipment delivered by the supplier must be packaged completely, and measures such as moisture-proof, moisture-proof, shockproof, rust-proof and anti-corrosion should be taken to ensure that the goods are intact after repeated handling and loading and unloading during long-distance transportation and arrive at the destination safely. The supplier shall bear all losses caused by damage, corrosion or deformation of the goods due to poor packaging and inadequate or improper protection measures.
6.2 Detailed packing list, certificate of approval and relevant technical data shall be attached to each packing box.
Seven. Technical services and liaison
7. 1 the seller shall provide technical guidance, technical cooperation, technical training and other services related to the inspection, installation guidance, start-up and commissioning, acceptance, operation and maintenance of the contract equipment in a timely manner.
7.2 The technical service personnel sent by the supplier to the site for service shall be those who have practical experience and are competent for this job.
7.3 The supplier shall be responsible for the losses caused by the technical guidance errors or negligence of the supplier's technical service personnel, or by the supplier's failure to dispatch technical service personnel as required.
Eight, quality inspection
8. 1 The supplier shall accurately and comprehensively check the quality, specifications, performance and quantity of the goods before delivery. 8.2 Within one day after the contract equipment arrives at the delivery place and is unloaded, the seller shall submit the product delivery acceptance form, and the buyer shall count and check the packaging, appearance and quantity of the goods according to the product delivery acceptance form. If it is complete and correct, the buyer shall sign for it. After the buyer signs for the goods, the responsibility of keeping the goods is handed over to the buyer. Any man-made damage during storage shall be borne by the buyer.
8.3 The supplier shall be responsible for unpacking and the buyer shall accept it. The Buyer shall confirm the contract equipment and accessories after acceptance according to Annex I: Technical Specifications and Configuration.
8.4 During unpacking inspection, if any damage, defect, shortage or disqualification (excluding the damage during storage) of equipment or components due to the supplier's reasons (including transportation reasons) is found, records shall be made, which shall be signed by the representatives of the supplier and the demander, with each party holding one copy, as the basis for the demander to claim for repair, replacement or compensation from the supplier.
8.5 If the Seller has any objection to the above-mentioned repair, replacement or claim of the Buyer, it shall raise it within 7 days after receiving the written notice from the Buyer; Otherwise, it is deemed that there is no objection to the above requirements. If there is any objection, the supplier shall send a representative to the site to reinspect with the buyer at its own expense within 7 days after receiving the notice.
8.6 If the representatives of the supply and demand sides fail to reach an agreement on the inspection records in the equipment inspection, the supply and demand sides may entrust an authoritative third-party organization to conduct the inspection, and the inspection results shall be binding on both parties. The inspection expenses shall be borne by the responsible party.
8.7 The Seller shall repair or replace the damaged, short or defective parts as soon as possible after receiving the buyer's request for repair and replacement according to the provisions in 8.2 to 8.6, and all expenses arising therefrom shall be borne by the responsible party.
8.8? The repair or replacement time of equipment or components caused by the supplier should be based on the principle of not affecting the progress of the project, otherwise it will be handled according to the clause 10.4.
8.9 The inspections mentioned in paragraphs 8.2 to 8.8 above are only on-site arrival inspections. If no problems are found or the supplier has replaced or repaired according to the requirements of the buyer, it cannot be regarded as the release of the supplier's quality assurance responsibility as stipulated in the contract.
8. 10 The risk of damage or loss of the goods shall be transferred from the supplier to the buyer after the unpacking inspection is completed.
9. Guide installation, equipment debugging, acceptance and after-sales service.
9. 1 the seller shall send professional technicians to guide the buyer's installers to install and debug the contract equipment on site according to the current relevant national standards and specifications, as well as the seller's technical data, inspection standards, drawings and instructions. In the whole process of guiding installation and debugging, the supplier must obey the on-site management of the buyer.
9.2 During the installation and commissioning of the contract equipment, all quality problems or safety problems caused by improper technical guidance of the seller shall be borne by the seller.
9.3? The seller shall be responsible for the potential defects that may cause damage to the contract equipment during the commissioning and operation of the contract equipment during the warranty period.
9.4 Within 7 working days after the supplier completes debugging and carries out on-load trial operation, the supplier will issue a debugging report, which will be signed by the buyer's representative, and then the buyer will issue an acceptance certificate. This acceptance certificate only proves that the performance, parameters and installation quality of the contract equipment provided by the seller can be accepted according to the contract requirements when the acceptance certificate is issued, but it cannot be regarded as the responsible release of potential defects that may cause damage to the contract equipment during the debugging and operation of the contract equipment. During the warranty period, the supplier shall be responsible for the above defects.
9.6 During the warranty period of equipment quality, the supplier shall provide timely and free maintenance services for various faults under normal use of equipment. All kinds of parts damaged by non-human factors should be replaced free of charge in time. The quality warranty period of the replaced parts shall be recalculated from the date of replacement, and the replaced parts shall enjoy quality assurance within three months after replacement or according to the remaining period of the original warranty period, whichever is longer. Man-made damage maintenance only charges for materials. In case of equipment failure, the Seller shall send the after-sales service personnel agreed in this contract to the contract equipment site within 48 hours to check the contract equipment and determine the equipment failure. Within two hours after fault diagnosis, notify the buyer of the fault situation and solution of the contract equipment orally or in writing. If the seller fails to eliminate the fault of the contract equipment within the promised time, the buyer reserves the right to claim compensation from the seller.
X. Warranties and claims
10. 1 The contract equipment provided by the supplier fails to meet the relevant provisions in Annex I of this contract after inspection by an authoritative third party agency entrusted by both parties. If the buyer requests to return the goods, the supplier shall not only return the full payment, but also bear the economic losses caused to the buyer. If the buyer does not request to return the goods, the supplier shall pay the buyer a penalty of 10% of the total contract price, and if the buyer's loss exceeds the penalty amount, the supplier shall compensate;
10.2? During the execution of the contract, if the operation of the contract equipment fails due to the technical data provided by the supplier or the guidance error or negligence of the supplier's technicians, the supplier shall bear all the responsibilities and expenses arising therefrom, as well as all the economic losses caused to the buyer.
10.3 the seller shall be responsible for the potential defects of the contract equipment during the quality guarantee period. Once such defects are found, the buyer has the right to lodge a claim with the supplier. At the same time, the supplier shall immediately repair or replace the claim documents of the buyer, and bear all the responsibilities and expenses arising therefrom and all the economic losses caused to the buyer.
10.4 if the supplier fails to deliver the goods according to the delivery date agreed in the contract due to reasons other than the buyer (except for force majeure), the buyer has the right to collect liquidated damages from the supplier, and the late payment of liquidated damages does not relieve the supplier from continuing to perform the delivery obligations according to the contract.
10.5 the supplier guarantees that the buyer will use its equipment, services and any part thereof in China without being accused of infringing the patent right, trademark right or industrial design right. If any third party makes infringement allegations, the supplier shall bear all legal consequences.
XI。 insurance
1 1. 1 The supplier shall take out "transportation insurance" for the contract equipment with the insurance company as the beneficiary.
1 1.2 when the contract equipment is damaged, missing parts or other insurance accidents during transportation, the seller shall be responsible for claiming compensation from the insurance company.
1 1.3 For the contract equipment not covered by the insurance company, the seller shall provide the buyer with defective parts free of charge.
Twelve. Alteration, modification and termination of the contract
12. 1 Once this contract comes into effect, neither party shall make any unilateral modification to the contents (including annexes) of this contract without authorization.
12.2 The responsible party shall bear the expenses arising from the change, modification or suspension of the contract.
12.3 if the buyer returns the goods without authorization due to the return or termination clauses agreed in this contract, the buyer shall pay the seller a penalty of 20% of the price of the returned equipment.
12.4 if the goods cannot be delivered due to the supplier's reasons, the supplier shall pay the buyer a penalty of 20% of the price of the contract equipment that cannot be delivered, and compensate the buyer for the direct economic losses caused thereby.
Thirteen. force majeure
13. 1 If the performance of contractual obligations is affected by force majeure events, the period of delay in performance of contractual obligations is equivalent to the time affected by the force majeure events, but the contract price cannot be adjusted due to the delay of the force majeure events.
13.2 the party affected by force majeure shall notify the other party of the force majeure event in writing within three calendar days after the force majeure event occurs, and issue the corresponding official certification documents.
Fourteen Settlement of contract disputes
All disputes arising from this contract shall be settled by both parties through friendly negotiation. If negotiation fails, it shall be submitted to Chengdu Arbitration Commission for arbitration or bring a lawsuit to the court where the contract is signed. (Arbitration or litigation can only be one of them)
14.2 The expenses incurred in the above process shall be borne by the losing party.
14.3 during the arbitration or court hearing, this contract shall continue to be performed except for matters submitted for arbitration or court hearing.
Fifteen. Entry into force and termination of contract
15. 1 This contract shall come into effect after being sealed by the buyer and the seller and signed by their representatives.
15.2 this contract shall be terminated after the responsibilities and obligations of both parties are fulfilled.
Sixteen. others
16. 1 All annexes to this contract are an integral part of this contract and have the same legal effect as this contract.
16.2 Without the prior consent of the other party, neither party may transfer part or all of its rights or obligations under this contract to a third party.
16.3 all written documents submitted by either party to the other party in this contract shall be sent by letter, telegram or fax, and shall be deemed to have been formally accepted by the other party after being confirmed and formally replied by the other party.
16.4 any software provided by the supplier to the buyer under this contract shall belong to the property of the supplier or other relevant software providers, and the buyer and the ultimate owner of the equipment shall only have the right to use it and shall not transfer it. The supplier guarantees that the software provided to the demander and the ultimate owner of the equipment is genuine, and provides the maintenance and upgrade of the software to the demander and the ultimate owner of the equipment free of charge.
16. During the performance of this contract, all supplementary agreements and letters become annexes and effective components of this contract once they are signed, sealed or confirmed by both parties, and their effective date is the date of signing or confirmation by both parties.
16.6 this contract is made in quadruplicate, with the supplier holding two copies and the buyer holding two copies. The annexes to this contract include:
(1) Annex I: Technical Specifications and Configuration
(2) Annex II: After-sales Service Commitment
Matters not covered in this contract shall be settled by both parties through negotiation or a supplementary agreement shall be signed with reference to the Contract Law and other relevant laws and regulations, and the supplementary agreement shall have the same legal effect as this contract.
Buyer _ _ _ _ _ _ _ Supplier:
Buyer: _ _ _ _ _ _ _
Seller: _ _ _ _ _ _ _
Address: _ _ _ _ _ _
Address: _ _ _ _ _ _
Postal code: _ _ _ _ _ _
Tel: _ _ _ _ _ _
Fax: _ _ _ _ _ _
Bank of deposit:
Remittance address:
Bank account number:
Bank of deposit:
Taxpayer registration number:
Account number:
Invoicing type:
Taxpayer registration number:
Legal representative:
Legal representative:
Signature representative:
Signature representative:
Date of signing:
Date of signing:
Model equipment purchase and sale contract 3
Party A (demander):
Party B (supplier):
Based on the principles of voluntariness, equality, mutual benefit, honesty and credibility, Party A and Party B have reached the following terms of the contract through full friendly negotiation, so that both parties can abide by them.
First, the subject matter of the contract.
The product name purchased by Party A is-See the list for detailed equipment configuration; Equipment not listed in the list is not included in the contract supply; If Party A needs it, it will be priced separately;
Second, the contract price and payment.
1, and the total contract price is RMB _ _ _ _ _ _ _ (in words).
2. Pay a deposit of 30% of the total price after signing the contract;
3. Pay 60% of the total price after purchasing the equipment delivered by the recipient;
4. The retention money is 10% of the total price, and shall be paid within _ _ _ _ _ months after the equipment debugging is qualified.
Three. Equipment transportation and risk taking adopt-mode.
1. Party B consigns the goods on behalf of Party A, and Party A pays the freight directly to the transportation unit before unloading the equipment. Party B shall be responsible for loading the car and bear the risks before loading, and the risks after loading shall be borne by Party A;
2. Party B delivers the goods to the door and bears the freight, while Party A is responsible for unloading; The risks before unloading shall be borne by Party B, and the risks after unloading shall be borne by Party A. ..
Fourth, equipment delivery.
1. delivery time: the seller shall deliver the goods in _ _ _ batches within _ _ _ months after the contract comes into effect.
2. The seller shall fax the relevant contents of the contract equipment to the buyer before the delivery date, so that the buyer can prepare for receiving the goods.
Verb (abbreviation for verb) Equipment acceptance.
1. The equipment shall be accepted at the same time of delivery, and Party A shall sign for it on the acceptance sheet after confirming that the equipment and its ancillary equipment are correct;
2. If the product is found to be non-compliant, it should be reported in. Put forward a written objection to Party B within days;
Delivery of intransitive verb data.
The seller shall mail the drawings, materials, technical documents and other technical materials related to the contract equipment to the buyer within _ _ _ _ months after the contract comes into effect.
Seven, after-sales service.
1. Party B provides technical support and services for installation, debugging and maintenance;
2. Party B shall provide free on-site warranty service for 12 months from the date of acceptance. If the product is damaged due to quality problems during the warranty period, Party B shall be responsible for replacing it free of charge;
3. Equipment damage caused by wearing parts, human factors and material corrosion (phosgene, hydrofluoric acid, more than 40% naoh, kho concentrated solution) is not within the scope of free service.
Eight, force majeure.
When the performance of this contract is affected by fire, drought, earthquake, war and other force majeure accidents agreed by both parties, the performance period of this contract may be extended or terminated, and the liability for breach of contract may be partially or completely exempted as appropriate.
9. Liability for breach of contract.
1. If Party B delays the delivery for one day, Party B shall pay a penalty of% of the total value of the products not provided, with a maximum of 20% of the total contract value;
2. In case of overdue payment, Party A shall bear% of the total overdue payment as liquidated damages every day from the day after the due date, and the maximum liquidated damages shall not exceed 20% of the contract amount.
X. settlement of disputes.
In case of any dispute arising from the performance of this contract, if negotiation fails, the following option shall be adopted for settlement.
1. Apply to Zhengzhou Arbitration Commission for mediation and arbitration;
2. Bring a lawsuit to the people's court of the plaintiff's domicile.
XI。 Other considerations:
Party A: Party B:
Year month day:
Simple model of equipment purchase and sale contract 3 related articles:
★ 3 simple equipment purchase contract templates
★ 3 copies of simple equipment sales contract.
★ 3 model equipment sales contracts
★ Simple Edition of 3 Model Terms of Electrical Appliances Purchase and Sale Contract
★ 3 samples of common equipment sales contract.
★ 3 samples of equipment supply contract
★ 5 simple old equipment sales contracts
★ Simple kitchen equipment sales contract model essay 3 latest.
★ There are 3 model clauses in the ordinary version of the pump equipment sales contract.
★ 5 practical old equipment sales contract templates