Internal contracting contract is the enterprise in order to achieve certain production and management objectives, according to the principle of the unity of responsibility and rights, by the enterprise as the contractor will be the enterprise contracted to the contractor signed the contract. So how much do you know about the internal contracting contract? What to pay attention to in general? If you are not sure, the following is my internal contracting contract for you to organize, welcome to read.
↓↓↓ Click to get more "internal contracting contract " ↓↓↓↓
★ Internal employee contract model
★ Company internal contracting contract
★ Engineering internal contracting contract
★ Internal contracting agreement Model
Internal contract agreement agreement Model 1
The contract unit: hereinafter referred to as Party A Residential town village group Party B
In order to improve the internal production responsibility system, strengthen management, the implementation of the task, by the consensus of the A and B parties, the finished product workshop in the kiln in the year 20_ task by the B to participate in the contracting, it is clear that the responsibilities and obligations of the A and B parties. A and B responsibilities and obligations, A and B voluntarily entered into the following contract terms.
First, the form of contract
1, individual contracting, safe operation without accidents.
2, brick billet into the kiln, quality and quantity, and obey the arrangements. 3, against the contract situation, according to the actual settlement.
Second, contracting indicators and price standards (unit: ten thousand / yuan) 1, the annual kiln into the task of 14 million, for 14.5 million. (Specifically based on the burning and roasting)
2, every day, people, classes, production guaranteed completion. 3, each into the kiln 10,000 pieces of red brick compensation for 31 yuan. (kiln shed for $, specific site implementation), the above standards include one, two whole area and two development zones of the brick billet into the kiln, rain no one cart, other no longer have shi workers plus, sunny day billet room billet private kiln deductions of 10 yuan per car.
Third, the wage settlement
1, Party B wage settlement always to Party A red brick into the actual number of settlement.
2, monthly table in the next month 10-15 issued 70% of last month's wages (special circumstances special treatment).
3, the balance of 30% of the wages for the withholding money to stay in the factory, midway through the behavior of no model rules, to the end of the year, a one-time settlement to cash, such as stopping halfway through the withdrawal of the class, to stay in the factory of the withholding of all the money as an automatic relinquishment.
Fourth, the rights and obligations of Party A
1, to assist Party B to do a good job of safety education awareness, all according to the rules. 2, for the production of Party B to provide more than medium-sized tools and equipment.
3, have the right to check the implementation of the contract and product quality and task completion.
4. Strengthen the management of Party B's safety precautions and issue labor protection supplies.
5, disobedient managers, the right to terminate the contract at any time, all according to the contract. Fifth, Party B's responsibilities and obligations
1, in the production must be safe and civilized production, the occurrence of safety accidents, the responsibility for accidents and economic losses and the consequences of accidents, after the investigation of who should be borne by who bear.
2, obey the party and the kiln master's arrangement of guidance, no right to interfere in the enameling matters and there are dry billet there to drag, cancel the past to seek near the bad atmosphere.
3, adhere to the morning and afternoon shifts into the kiln, such as insisting on half-time, the intangible losses caused by the party to bear full compensation or wages directly down 2 yuan / million.
4, spring production began to borrow the Party's production tools, to the end of the year, such as the number of original quality to the Party's inventory, or full compensation according to the original price.
5, the Party issued the safety protection equipment to normal wear, found that a failure to wear a deduction of 50 yuan.
Six, other matters
1, this contract is signed by both parties to enter into force, and that is legally binding, no party shall not privately adjust the task and wage standards, if there is a breach of contract by 25% of the total wage for liquidated damages.
2, the contract was signed to pay Party A deposit of 200 yuan, at any time to listen to the notice into normal production. Docking notification refused to be present in addition to deducting the deposit, and to bear all the losses resulting from the delay in compensation.
3, the validity of the contract from the date of signature to the end of the 20 _ annual production of Party A, the two sides to clear the accounts of the contract null and void.
Party A:
Witness Unit:
Party B: Tel:
Signing Time: 20_Yuan month twenty
Internal Contracting Agreement Sample 2
Party A:
Party B:
Today, there is a party to the construction of the project by the party A contracted part of the construction project. Party B contracted part of the construction project, in order to ensure the smooth progress of the project, clear responsibilities, rights and benefits of both parties, the two sides agreed to sign the following terms of the agreement, *** with the compliance with the implementation.
First, the project overview
1, Project Name: 2, Project Location:
Second, the scope of contracted construction
Third, the form of contracting
Fourth, the form of settlement and the contract price
1, the contract price (tentative) for: yuan, capitals:
2, the settlement of this project is:
V. Payment
The construction process of the project according to the image progress payment, completion and acceptance of payment to the contract cost of %, settlement payment to the settlement price of %, the balance of the settlement in the settlement of the total amount of payment after the completion of the year to the settlement price. The project warranty period for a year, the warranty is %, the warranty in the project warranty period expired within 30 days if there is no quality problem one-time interest-free return.
Six, the project duration
1, the project start date for the month of January, the completion date for the month of January, the contract duration of 35 days, due to the delay caused by Party B, every day of delay, for Party B to impose a fine of % of the total contract price of the project.
2, Party B must be developed by the construction of the overall progress of the construction plan on time into the construction, such as Party B can not be on time into the construction, every day of delay, Party B in 500 yuan fine.
VII, the quality of the project
1, Party B must be issued by the state unified construction acceptance specification and quality inspection standards, construction blueprints and design changes carefully constructed to achieve 100% qualified standards, and pay attention to the protection of finished products in the construction, such as the occurrence of contamination damage, the responsible party should be repaired within the time limit, and bear the corresponding economic losses.
2, Party B must meet the quality level requirements of Party A in the entire project, Party A will be a full-time quality inspector for acceptance of its construction, such as each acceptance of unqualified sub-items, Party B must rework, and its rework materials and delay in the loss of time borne by Party B.
3, for Party B in the construction process, resulting in significant losses and major engineering quality problems, Party A will be held responsible for Party B and Party B accompanied by Party A all losses, Party A has the right to retire Party B out.
VIII, Party A obligations and responsibilities
1, responsible for providing relevant construction drawings, construction programs, construction quality, overall progress and construction scheduling plan. Responsible for coordinating the relationship with the construction, supervision and other relevant units.
2, assign the construction technology, quality inspection personnel responsible for the construction quality, progress and civilized construction supervision, inspection work, in violation of the provisions of the Party's construction site management, or not according to the design requirements and relevant construction engineering norms and standards of construction, have the right to order its stoppage, rectification or return to the repair, if Party B does not comply with the instructions of the Party A, the Party has the right to withdraw from the Party A out of the field and Party B bear all the economic and financial costs caused by termination of the agreement midway. If Party B does not obey Party A's instructions, Party A has the right to remove Party B from the site, and Party B will bear all the economic losses caused by the termination of the agreement.
3, responsible for the preparation of project information and budget, due to the problem of information budget, all the responsibility of Party A is responsible for.
4, such as Party A to buy materials and equipment, in Party B put forward the list of materials and equipment needs, must be purchased within two days.
IX, Party B's obligations and responsibilities
1, Party B's construction site and dormitory health must meet the requirements of the higher level of civilized site standards, must strictly abide by the relevant provisions of Party A to achieve civilized construction, the construction of the section of the surface every day must be done to the end of the work site clear, and in the process of construction to accept the competent authorities at all levels of the various inspections and penalties.
2, educate our workers strictly according to the safety production norms and safety production procedures for construction, construction operations before the inspection of machinery and equipment and construction tools to ensure the safety of workers, Party B to provide their own safety facilities and protective equipment, such as the occurrence of safety accidents, and all the costs borne by Party B.
3, Party B contracted within the scope of the purchase of materials must be notified to Party A 2 days in advance, by Party A and Party B and the relevant construction unit **** with the inspection and sign a written material can be purchased, Party B purchased materials must be in line with the inspection of the quality of the German Party and specifications, and to meet the national norms of the required qualification standards. If according to the agreement to be purchased by the material, Party B must be 2 days in advance of the material and equipment list of written reports to the Party.
4, Party B personnel must strictly abide by the construction site of the relevant provisions of the relevant public security regulations and Party A relevant internal regulations, where Party B violation of the relevant fines will be borne by Party B. If there is a fight or brawl at the construction site, Party B will not be responsible for it. If the phenomenon of fighting and brawling occurs in the construction site, Party B will be penalized 1000 yuan each time. In the construction process, such as theft occurs, each time the amount of 10 times the amount of penalties incurred by Party B, and Party B promptly write a written report, the circumstances are serious according to the law reported to the public security organs.
5, is responsible for providing workers with the required beds and labor insurance supplies. Payment of personal accident insurance for workers.
6, Party A provided materials to Party B, Party B is responsible for safekeeping, such as waste or loss of materials by Party B at the price of compensation;
7, is responsible for the completion of the delivery of the finished product before the construction of the protection of the work and completion of the delivery of the warranty work.
X. Supplementary Agreement:
XI. Disputes arising from the fulfillment of this Agreement shall be resolved by mutual agreement.
This agreement is in duplicate, A and B each sign a copy, both sides signed (seal) after the entry into force.
Party A: (signature or seal) Party B: (signature or seal)
Year month
Internal contracting agreement model 3
Party A: Jiangxi Chuangye Construction Engineering Company Limited
Party B: Zeng Haisheng?
In order to improve the company's staff work enthusiasm, in accordance with the "Chinese People's Republic of China *** and the State Contract Law", "Chinese People's Republic of China *** and the State Construction Law" and other relevant laws, administrative regulations, follow the principle of equality, voluntariness, fairness and honesty and credit, the two sides on the construction of the construction project construction management matters consensus, Party A agreed to hire Party B as Yunshi Shandong Mountain Hope Primary School Village School Children's Palace Repair Engineering project department in charge. In order to ensure the quality of the project and safe production, the two sides agreed to determine the following terms, in order to *** with the compliance:
1, Party B should be Yunshi Shanshan Hope Primary School Village School Children's Palace Repair Project contract cost of 1% (more to the final settlement audit price shall prevail, less to the contract cost shall prevail) calculated to turn over to Party A pure management personnel fee, the cost of this cost in the first project progress payment One-time deduction.
2, Party B shall fully fulfill all the terms of the construction contract and agreement signed by Party A and the construction unit, and Party B shall be responsible for any consequences of the project due to Party B's behavior.
3, because of Yunshi Shandong Mountain Hope Primary School Village School Children's Palace repair works and other related fees, Party B is responsible for the payment of the specific payment scope and proportion according to the tax department and other relevant departments and Party A's financial system to determine the requirements.
4, the implementation of the project funds for special purposes, no party shall not be misappropriated, the project funds must all enter the bank account designated by Jiangxi Chuangye Construction Engineering Co. Party B withdrawal of construction funds, should be three working days in advance to notify Party A, and provide Party A construction invoices, tax certificates, state tax consumables certificate and signed by Party B receipt and payment vouchers. Party A, after examination, if Party B is not found to be in breach of contract, after deducting the corresponding tax, that is, to Party B for the payment of the project.
5, Party B in the construction contracting period of all the economic and legal liabilities (including but not limited to casualties, debt disputes, property damage, etc.) are borne by Party B, Party A does not bear any responsibility.
6, Party A and Party B must strictly abide by the management and use of funds, the unauthorized misappropriation of funds for the project is considered a breach of contract, either party has the right to pursue civil and criminal legal responsibility.
7, Party B shall pay the wages of the migrant workers on time and in accordance with the actual, if Party B defaults on the wages of the farmers, Party A has the right to deduct the corresponding amount of money in the project, and impose a fine of 10~600,000 yuan, and all the consequences caused by Party B is responsible for.
8, Party B must be in accordance with the relevant state engineering acceptance specifications for construction and with the various functional departments to do a good job of project management, to ensure the quality of the project and safe production. Party A has the right to inspect the quality and safety of the project from time to time, the resulting travel expenses borne by Party B.
9, Party B must rectify the quality and safety of the project in accordance with the requirements of Party A, and will rectify the results reported to Party A, Party A has the right to organize personnel to rectify the results of Party B to conduct a review (resulting in travel expenses borne by Party B), such as unqualified or not to rectify the review, Party A has the right to freeze the Party B project funds until Party B rectified the qualified, the project funds to be thawed use.
10, Party B should seriously do a good job of safety construction, strict compliance with the rules and regulations, to eliminate the occurrence of casualties and safety accidents. If any casualty safety accidents occur during the construction period, Party B shall bear all the economic and legal responsibilities. Party A only participates in the handling and mediation of the accident and does not bear any economic responsibility. Party B will be responsible for all losses of the company including but not limited to economic and reputation.
11. If Party B has the need, Party A shall assign the constructor and five members to assist Party B to supervise the quality and safety of the project site. Wages, transportation costs, accommodation and food costs are the responsibility of Party B, of which wages at a monthly rate of 7800 yuan / member of the standard by Party B to be paid in advance to Party A in the form of a half-yearly payment. Party B shall also pay travel expenses to Party A's constructor and five members if necessary due to national statutory holidays and duty reporting. Remarks: The construction unit needs personnel to inspect the site, and all the expenses will be paid by Party B.
12, Party B, such as late payment of taxes and other fees, each day late, pay 10% of the fees payable to Party A as liquidated damages, more than 30 days late, Party A may terminate the contract and have the right to require Party B to compensate for losses, such as Party B refused to assume the responsibility for the breach of contract, Party A can be directly deducted from the amount of money due to pay the works of Party B.
13, Party B should also be paid to Party A construction engineer and five major personnel travel expenses.
13, Party B shall not set up a private account, private engraving of the official seal, shall not be signed in the name of Party A agreements, contracts and any other documents related to Party A. If one of the above violations, Party B shall pay 20~600,000 yuan as liquidated damages and compensate for damages, and in serious cases, hand over to the judiciary to pursue criminal responsibility.
14, Party B in the construction period, such as the occurrence of a casualty accident, Party A can withhold Party B's project payment of 60 ~ 1.2 million yuan, to be Party B through the proper way to deal with the accident, according to the losses suffered by Party A, and then specific settlement.
15. If Party B is responsible for third party's debt, Party A has the right to deduct Party B's corresponding project payment. And Party B must compensate Party A for credit loss of 20 to 60 million yuan.
16, since the completion of the project, Party B should be in the scope of the project life according to national laws and regulations of Yunshi Shandong Mountain Hope Primary School Village School Children's Palace Repair Project project warranty responsibility.
17, this contract from the date of signing of the two parties to take effect, this contract in duplicate, Party A executes a copy, Party B executes a copy, with the same legal effect.
18, Party A's management system for the project department as an annex to this contract, and this contract has the same legal effect.
20, the disputes in this contract for the People's Court of Party A's domicile.
Legal representative: Mobile phone number:
A copy of Party B's ID card:
Date: November 23, 20_ Party A: Party B (signature, handprint)
Sample Agreement on Internal Contracting Contracts 4
I. The main body of the part
1, the name of the A and B parties:<
(1) Party A: Shandong Shuangsheng Food Co., Ltd, legal representative:
(2) Party B; Contractor:
2, contracted genera period: December 31, 20__ to December 31, 20__
3, contracted items:
4, the principle of: according to the law of independent operation, self-supporting profit and loss;
5, Contracting method: risk money collateral contracting, over-penalty section award;
6, Party B collateral: 40% of the contracting period of the workers according to the current set of monthly wages, the contractor according to the contracted amount of 5% of the payment to Party A;
Second, the initial management of the contracting before the contracting
1, clean up all of the existing resources of Party B, the latter is attached to the breakdown of A and B party cleaned up;
2, the approved contracting Party B Should use the resources, attached to the verification of the number of detailed information;
3, A and B resources handover procedures, attached to the handover of detailed information.
Third, the main content of the contract:
1, the scope of business:
2, business objectives:
3, contracting requirements:
4, the assessment of the implementation of:
(1) assessment procedures:
(2) assessment of the basis:
(3) assessment of the implementation of the monitoring unit:
5, rewards and penalties:
(3) assessment of the implementation of the supervision unit:
4, the contracting of the contract:
5, the contracting of the contract:
5, the contracting of the resources of both parties. Rewards and penalties:
(1)Prize for completing the task:
(2)Penalty for failing to complete the task:
(3)Prize for exceeding the task:
(4)Penalty for terminating the contract to Party B's security deposit;
(5)Other penalties for breaching the contract:
Fourth, the rights and obligations of Party A
1.Right:
(1) ) Supervision of Party B's operation and distribution rights;
(2) found in breach of contract has the right to terminate the contract;
(3) Personnel management rights;
(4) develop supervision and assessment of the management approach;
2. Obligations:
(1) Provide operating resources;
(2) Provide accounting and assessment of the management approach;
(3) Assist Party B to complete the contracting;
(4) Be responsible for breach of contract.
V. The rights and obligations of party B
1, rights:
(1) internal management and distribution rights (but the contractor enjoys up to three times the average salary);
(2) internal personnel management rights;
(3) supervise the supply of materials to party A in a timely manner and the quality of qualified price reasonable.
2. Obligations:
(1) operate in accordance with the law;
(2) provide internal management system and accept Party A's supervision;
(3) provide the internal distribution program;
(4) report regularly to Party A on business information;
(5) implementation of the company's various systems;
(6) breach of contract to be responsible for.
Six, other
1, the two sides shall not unilaterally change the terms of the contract for any reason, otherwise the parties bear full responsibility;
2, the outstanding issues, the A and B negotiated to resolve;
3, notarized notary public.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________ year ____ month ____ day _________ year ____ month ____ Day
Sample Agreement for Internal Contracting Contract 5
Party A: _________
Party B: _________
Party A gives the construction task of the ________________ project to Party B, on behalf of the company to deal with and bear the quality, progress, safety and other technical and economic responsibilities, recognized by the two sides discussed and reached the following agreement:
I. Name of the project: _______________________
II. Location of the project: _______________________
III. Responsibilities of Party A:
1. Party A is responsible for handling construction project various formalities.
2. Responsible for the construction of various mechanical equipment.
3. Help to solve the difficult problems of the project.
4. Supervise Party B to improve safety.
5. To help Party B for the completion of acceptance of various construction procedures.
Fourth, Party B's responsibility:
1. Completion of the construction contract signed by the owner and the construction party.
2. Responsible for personnel, quality, safety and tax on the project.
3. Responsible for the disposal of funds on the construction site.
4. Responsible for the management and maintenance of machinery and equipment on the construction site.
V. Accounting: internal contracting project agreement by the fine information network!
The company's sites separate accounting, profit and loss of self-responsibility, the construction side of the construction funds paid by Party A can not be used privately. The costs incurred at the site are the responsibility of the contractor.
Sixth, the funds and accounts management
Each site to submit the total price of the coordination fee _________%, is the company's administrative personnel salary costs.
VII. Payment time:
Each site regardless of how much the construction party owes, must be collected in two, the main body of the actual payment of half, the initial inspection must be paid before.
VIII, project acceptance:
Party B must pay attention to the quality of the project, safety, as a hundred years, quality first principle, subject to the Party's administrative management, to accept the Party's supervision and inspection of quality and safety.
Nine, information:
Party B's house is completed, must hand over a complete set of completion information and record certificate by the company for safekeeping. Internal contracting project agreement organized by the fine information network!
X. This agreement is in four copies, two copies for each party.
Party A (signature): _________
_________ year ____ month ____ day
Party B (signature): _________
_________ year ____ month ____ day
Sample Agreement for Internal Contracting Contracts Related Articles
★ Internal contract agreement model 3
★ Engineering internal contract model 3
★ The company's internal contracting business contract model essay compilation
★ 5 practical contracting business contract model
★ Simple internal contracting contract the latest model
★ Internal contracting contract model 3 script"); hm.src = "/hm.js?fff14745aca9358ff875ff9aca1296b3"; var s = document.getElementsByTagName("script")[0]; s.parentNode. insertBefore(hm, s); })();