In the era of continuous progress, contracts have more and more uses. Signing a contract can restrain the parties from behaviors that harm the interests of the other party. But do you know how to write well? The following are 3 articles about film and television production contracts. They are for reference only. You are welcome to read them. Film and Television Production Contract Chapter 1

Contract number:

Customizer (referred to as Party A):

Producer (referred to as Party B):

< p> Based on the principle of mutual benefit and reciprocity, Party A and Party B have reached the following agreement through friendly negotiation:

1. Party A entrusts Party B to shoot and produce a TV commercial (feature) film, the length of the film, and the length of the film. Party A provides master tapes (which Party B keeps dry on behalf of Party B) and DVD/VCD discs.

2. Party A’s rights and obligations:

Party A must pay Party B production costs in the sum of RMB (lowercase RMB).

Party A shall provide Party B with relevant information required for production and ensure the authenticity and legality of the information.

Party A needs to organize and arrange the shooting site, clarify specific shooting requirements, and cooperate with Party B on-site shooting. If the shooting time and effect are affected due to poor organization and arrangements, Party A will bear the responsibility.

During the review period, Party A has the right to request Party B to make partial modifications without departing from the script.

3. Party B’s rights and obligations:

Party B must strictly follow Party A’s script requirements for filming and production, and all technical indicators of the finished film must meet the broadcast requirements. If any Party B shall bear full responsibility for quality problems and take corresponding remedial measures.

If the film cannot be completed on schedule or affects the quality of the film due to Party A's reasons, and Party A makes a request for remediation from Party B, Party B has the right to refuse or make a compensation request to Party A.

Party B is not allowed to change the script at will during the production period. If this causes Party B’s workload to increase or the film delivery time to be delayed, Party B has the right to require Party A to pay additional fees.

Party B shall not disclose relevant information provided by Party A to outsiders, and shall keep Party A’s business information absolutely confidential.

IV. Payment and film review methods:

1. Payment method:

When both parties sign a formal contract, Party A shall pay the down payment to Party B, calculated as follows: RMB yuan (lowercase ￥); Party A will settle the entire balance after the film is reviewed and approved, and it will be calculated in RMB yuan (lowercase ￥).

2. Film review method:

Within one working day from the date when Party A and Party B formally sign the contract, Party B will complete the production and deliver the film to Party A for review.

5. Other terms:

This contract will take effect from the date of signature by Party A and Party B.

This contract is made in two copies, each party holds one copy, and has the same legal effect.

Unfinished matters shall be resolved through negotiation between the two parties in the spirit of friendly cooperation. If negotiation fails, the matter shall be resolved through litigation procedures. The court with jurisdiction over the contract shall be the court at the place where the contract is performed.

Party A: Party B:

Signature (seal): Signature (seal):

Date: Date: Film and Television Production Contract Chapter 2

< p> Party A: (Principal Party) xxxxxx Co., Ltd. Party B: (Filmmaker) xxxxx Media Co., Ltd. Project: Publicity and training video CD shooting

In accordance with the Contract Law of the People's Republic of China and the People's Republic of China " and relevant laws and regulations. Party B accepts Party A's entrustment. Regarding the entrusted shooting matters, both parties have reached consensus through negotiation, signed this contract, and will abide by it.

1. Contract content and requirements:

Party A entrusts Party B to shoot and produce promotional and training video CDs. The length of the film is minutes.

2. Project filming:

The overall project filming time: from January 20, 2020 to January 20, 2020.

(Calculated from the date of receipt of advance payment)

3. Project filming fee:

1. The total cost of filming this project is RMB

2. After signing this contract, Party A will pay 50% of the total design fee to Party B, calculated Party A shall pay the remaining 50% of the project production cost in RMB yuan when Party B completes and delivers the CD in accordance with the production requirements.

IV. Rights and obligations of both parties:

Party A’s rights:

1. Party A has the right to make suggestions and ideas for Party B’s shooting, so that the works shot by Party B are more in line with Party A’s requirements ; 2. Party A shall provide Party B with relevant information required for production, and ensure the authenticity and legality of the information;

3. The video script must be approved and signed by Party A before filming can be carried out. Party B should strictly follow the signed script for filming; if the script needs to be changed after it is signed and confirmed, Party A will be responsible for the costs incurred due to the changes.

4. During the review period, Party A has the right to require Party B to make post-editing changes to the finished film without departing from the script.

Party A’s obligations:

1. Party A is obliged to pay relevant fees in accordance with the contract;

2. Party A is obliged to provide relevant information or other relevant Provide information to Party B.

Party B’s rights:

1. Party B must strictly follow Party A’s script requirements for filming and production, and all technical indicators of the finished film must meet broadcast requirements.

2. If the film cannot be completed on schedule or affects the quality of the film due to Party A's reasons, and Party A makes a request for remediation to Party B, Party B has the right to refuse or make a compensation request to Party A;

3 During the production period of Party B, Party A is not allowed to change the script at will. If this increases Party B's workload or delays the delivery time, Party B has the right to require Party A to pay additional fees;

4. Party B shall not leak Party A's information to the outside world. The relevant information provided by Party B shall be kept absolutely confidential;

5. Party B has the right to require Party A to pay corresponding amounts as agreed in the contract;

6. Party B shall The photographed work enjoys copyright and has the right to display Party B's name at the beginning or end of the promotional video, and has the right to require Party A not to use the photographed work before the payment is paid in full.

Party B’s obligations:

Party B must film and produce the works in accordance with Party A’s requirements; 2. Party B must deliver the filming and production works on time as agreed in the contract.

5. Intellectual property rights agreement:

1. Party B has the copyright to the completed work. After Party A has settled all fees for the commissioned photography, Party B can automatically transfer the copyright of the work to Party A;

2. Before Party A has paid off all commissioned photography fees, the copyright of the work shot by Party B will belong to Party A. Party B, Party A does not have any rights to the work;

3. If Party A uses or modifies the work shot by Party B without authorization before the balance is paid, Party B shall have the right to infringe the rights in accordance with the "China Pursuant to the Copyright Law of the People's Republic of China and the People's Republic of China, Party A shall be held legally responsible;

4. After Party A has settled all costs for the entrusted filming and production, Party A has the ownership, use rights and modification rights of the work.

Six. Liability for breach of contract:

1. If Party A terminates the contract before the first draft of the filming work is completed, the prepaid fees have no right to be returned; if Party A terminates the contract after Party B completes the first draft of the work, it shall pay the full amount of the filming fees Production costs;

2. If Party B terminates the contract early without justifiable reasons, all fees collected shall be returned to Party A;

3. After Party B completes the video image, Party A The party shall pay the balance in full as stipulated in the contract. If one day is overdue, a penalty of 10% of the total contract amount will be paid. If either party breaks the contract after signing the contract, it will pay the other party 100% of the total contract amount as liquidated damages.

7. Dispute issues:

If a dispute arises between Party A and Party B due to the performance of this contract, it shall be resolved through friendly negotiation. If negotiation fails, either Party A and Party B may submit a request for arbitration.

Eight. Effectiveness of the contract:

The contract attachment is a part of this contract. This contract is made in two copies. Party A and Party B each hold one copy. It will take effect from the date of signature and seal by both parties and has the same legal effect.

9. Supplementary Provisions:

This contract does not include special aerial photography, underwater photography, crane and other shooting projects. If Party A requires it, both parties will separately agree on specific matters and fees based on market conditions.

(Party A): (Party B):

Legal representative: Legal representative:

Telephone: Telephone:

Ben Contract Signing Date: Year, Month, Day Film and Television Production Contract Part 3

Contract Number:

Party A:

Party B (Contractor) Name:

Party B (contractor) code:

Party A’s business undertaker:

Signing date:

Party A (client):

p>

Party B (Contractor):

In accordance with the Contract Law of the People's Republic of China and relevant regulations, both parties have reached an agreement through friendly consultations based on the principles of good faith, equality and mutual benefit. For the film and television project (VCR) production entrusted by Party A to Party B, Party A agrees to sign this contract at the location of Party A and agree to abide by it.

1. Design and production of video projects (multiple videos need to be listed separately):

Video (VCR) 1:

Video name: Video format:

p>

Production specifications: Production length (seconds):

Project language: Delivery format: □Network transmission □Data tape □CD □Others

Background music: Production requirements Follow attachments and production scripts.

2. Film production period:

1. The estimated production period is days. Party B will start production on day, month, year, and it will be completed and delivered to Party A on day, month, year.

2. If Party A is overdue in delivering film production-related materials to Party B or overdue advance payment, the production period may be extended accordingly. If the production time is delayed due to weather or other force majeure factors, both parties will resolve it amicably.

3. Provision of film production materials and film production requirements:

1. Party A shall deliver all materials and pictures required for film production materials to Party B, Party B must sign or confirm by email.

2. When signing this contract, Party B shall deliver the production script of this contract to Party A, which shall be signed and confirmed by both parties as an attachment to this contract. The production script should include Party A’s advertising production requirements, creative requirements, etc.

3. During the production process, Party A provides Party B with Party A’s related products, corporate professional texts and corporate texts, pictures, addresses, phone numbers and other information needed for the production of the video.

4. After the video production is completed and delivered to Party A, the copyright of the video belongs to Party A. Party A has the right to enjoy the distribution rights, publishing rights and original material rights of all films.

5. Party B shall produce in strict accordance with Party A’s production requirements to ensure that the picture quality and technical quality of the film meet the standards agreed upon by both parties. The technical indicators of the completed film shall not be lower than the standards determined by Party A's film production requirements.

6. Party B is responsible for presenting all script creativity, translation, refinement, lines (Chinese and English), split shots, and subtitles through the film.

7. Party B guarantees that the copyright of the production content is legal (including: images, music, dubbing, and actor portrait rights, etc.).

IV. Production costs and payment methods:

1. The project design and production costs*** are in RMB (RMB) and shall be paid by Party A.

1.1 The project requires an advance payment, the first payment is % of the total amount, RMB_______ yuan (i.e. RMB: ___________ Yuan), Party A pays Party B on the day the contract becomes effective, so that Party B can invest in production and implementation as soon as possible .

1.2 The balance is % of the total amount, RMB_______ yuan (i.e. RMB: _______________ Yuan), and shall be performed in accordance with the following clause 2 of the production cost and payment method of this contract.

2. Party B provides Party A with samples without LOGO. Within 15 working days after Party A's written review and acceptance, Party A will pay Party B the balance of production *** in RMB (RMB).

3. Party B shall provide Party A with a formal invoice for the full amount of this contract before Party A makes payment. If payment is delayed due to Party B’s failure to provide a legal formal invoice, Party A shall not be liable for breach of contract. Party B shall issue a written report on the failure to provide invoices and submit it to Party A for record.

4. Payment method: Party A shall pay by transfer in accordance with the requirements of the contract.

5. Acceptance standards and methods:

1. The acceptance standards shall be as attached to this contract after signed by Party A and Party B or confirmed by email.

1.1 Party A compares the film and television project documents designed by Party B according to the attachments of the contract and the standards of the promotional video content planning plan provided by Party B, and concludes that it is satisfied.

1.2 The film and television project document contains no text spelling, pictures, audio, and video errors (subject to the materials provided by Party A).

2. If Party A needs to modify the creative ideas, change the production script, or increase the film content and production length or other new production requirements during the production process, the two parties shall separately negotiate to determine the production period and increased production costs, etc. issues and sign a separate written supplementary agreement.

3. Party B will submit the finished video sample to Party A for review in the form of multimedia data within the agreed time. Party A's review

Should be completed within days, and if it meets Party A's film production requirements, Party B will provide Party A with the complete project production film after Party A's written or email confirmation.

4. If Party A has objections to the completed product, it shall submit modification opinions to Party B in writing or by email during the review period, and Party B shall complete the modifications according to Party A's modification opinions.

VI. Rights and obligations of both parties:

1. Party A’s rights and obligations:

1.1 Party A must provide relevant standard text and graphics required for the film Materials; commercial props, company scenes and staff specified in the film (including related products and related information materials in the film)

1.2 Party A must confirm the production script plan in a timely manner during the execution of Party B. Confirm in writing or propose written modifications within five working days; confirm the content of the meeting (PPM) discussion in a timely manner before production.

1.3 After Party B receives the confirmed content from Party A; especially the confirmed content in the PPM of Party A and Party B or Party A’s written confirmation of modification opinions, if Party A needs to add new content or modify the advertising film again, The costs incurred will be calculated based on the actual increased modification costs; at the same time, both parties will coordinate the time and method of re-delivery.

2. Party B’s rights and obligations:

2.1 Party B must be responsible for the entire implementation process, film quality and creative performance of the film. Strictly follow the script requirements of Party A.

Creative design, shooting and production, and all technical indicators must meet the broadcast requirements. If there are quality problems, Party B will bear the liability for breach of contract and take corresponding remedial measures.

2.2 Party B shall ensure that the finished film content it provides does not violate any laws and regulations or infringe upon the legitimate rights and interests of any third party (including but not limited to intellectual property rights). Otherwise, Party B shall be responsible for all consequences.

2.3 Party B must produce according to Party A’s requirements. If Party B needs to change the creative idea, it must be approved by Party A.

2.4 During the project period, Party B will make free modifications to the film production in accordance with the non-principle modification opinions proposed by Party A.

2.5 In accordance with the requirements stipulated in the contract, use Party A to browse the film and television files of the contracted film and television production project in a timely manner.

2.6 Complete the development of the film and television production project within the time limit specified in the contract, and promptly notify Party A for acceptance.

2.7 At the request of Party A during the acceptance period, unqualified areas shall be modified in a timely manner.

2.8 Confidentiality obligations:

2.8.1. Party B shall strictly keep this contract and any confidential information of Party A learned during its performance (including but not limited to any data, product technology data and other valuable information, etc.) and trade secrets, and shall not disclose the above information and secrets to any third party after the expiration of this agreement. Even if it is provided to personnel related to the performance of this contract, attention should be paid to keeping it confidential and limited to the scope necessary to perform the contract.

2.8.2 Within 15 days after both parties terminate the contract, Party B has the responsibility and obligation to return all originals and copies of the certificates, product specifications, drawings and other product information related to the film and television products entrusted by Party A. Failure to repay within the time limit will be regarded as Party B's private disclosure of confidentiality, and Party A reserves the right to further pursue the legal liability of the supplier.

2.8.3. Party B is responsible for keeping this contract confidential. Without formal written authorization from Party A, Party B shall not disclose all or part of the text or content of this contract to third parties (including agencies, Enterprises, organizations, collectives, individuals and other third parties), otherwise, Party A will pursue the supplier's liability for leakage through legal means.

2.8.4. This clause will remain effective within five years after this contract is terminated, rescinded, invalidated or confirmed to be invalid, and is legally binding on both parties.

7. Liability for breach of contract:

1. Both parties shall strictly perform the contract in accordance with the provisions of this contract. If one party breaches the contract, it shall bear the liability for breach of contract and compensate the other party for the breach of contract. losses caused to the other party.

2. If Party A makes late payment, Party A must pay Party B a penalty of 0.5% of the unpaid production fee for each day of the overdue period.

3. If Party B cannot complete the production or modification on time, Party B must pay Party A a penalty of 2% of the total contract amount for delay every day until the production project is completed. Liquidated damages may be deducted from unpaid amounts.

4. If Party B violates its obligations under this contract, Party B shall pay Party A a liquidated damages of 20% of the total contract amount.

5. If Party B is still unable to complete production or modification after 10 working days, Party A has the right to terminate this contract, and Party B shall issue a notice of termination on the date

The amount received will be returned to Party A in full and unconditionally within 5 working days, and liquidated damages for delay will be paid to Party A in accordance with the calculation method agreed in paragraph 3 of this article. The liquidated damages for delay will be calculated until the date when Party A issues the notice of termination.

8. Force majeure:

If the contract cannot be performed due to force majeure (disaster, war, etc.) during the performance period stipulated in the contract, the party unable to perform shall obtain the force majeure (disaster, war, etc.) After the legal proof of force majeure (disaster, war, etc.), the party will be exempted from liability for breach of contract, but the situation of force majeure (disaster, war, etc.) must be promptly notified to the other party within ten working days after the occurrence of force majeure (disaster, war, etc.).

9. Resolution of Contract Disputes:

If any dispute arises between Party A and Party B due to the performance of the contract, it should first be resolved through friendly negotiation; if negotiation fails, either party may file a lawsuit with the People's Court where Party A is located. litigation.

10. Other Agreements:

1. This contract shall take effect from the date of signature and sealing by both parties. The contract shall automatically expire upon completion of its performance. If representatives of both parties are responsible for signing the contract, they will also be responsible for the performance, supervision and communication of the project. The legal representative and person in charge of Party B bear joint and several liability for the performance of this contract.

2. The interpretation and execution of this contract shall be governed by the laws of the People's Republic of China.

3. Without the written consent of Party A, Party B shall not transfer any rights and obligations under this contract to a third party.

4. Matters not covered shall be carried out in accordance with the supplier cooperation contract, product quality assurance agreement, supplier code and other documents signed by both parties.

5. Any supplements, additions and modifications to the terms of the contract shall be made in writing and signed by authorized representatives of both parties.

11. Contract attachments:

Video production script, project progress control list

(There is no contract text below)

Party A :

Address: Party B: Address:

Fax:

Telephone:

Person in charge:

Account opening bank:

Account number:

Tax ID number:

Authorized representative (signature):

Signature date:

< p> Fax: Telephone: Person in charge: Account opening bank: Account number: Tax ID number: Legal representative (guarantor): Authorized representative (guarantor): Signature date: