Simple Cabinet Contract 1 Party A: _ _ _ _ _ _
Party B: _ _ _ _ _ _
I. Design
1. The designer of Party A will go to the site of Party B to measure the dimensions, and design and draw the floor plan and three-dimensional renderings according to the structure of Party B's house and the water route map provided.
2. After Party B confirms the drawings, Party A shall be responsible for instructing Party B to reserve the position of accessories and avoid the position of water and electricity pipelines, and Party B shall cooperate with Party A to reserve the above positions. If Party B brings its own electrical appliances, it shall inform the designer of Party A of the corresponding dimensions before placing an order, and the design will be completed after Party B signs the drawings.
Second, the mode of payment.
1. Both parties shall sign the manufacturing contract after determining the water, electricity and structural scheme. Party A is responsible for the preparation and production of boxes, and Party B must pay off the payment for the products, totaling RMB _ _ _ _ _ _ _ _ _ _, and the contract will come into effect.
2. Before installation, Party A shall confirm the installation conditions with Party B by telephone in advance, and then determine the installation date. Party B shall clean the kitchen in advance and put the self-purchased accessories on the installation site in advance.
Third, production.
1. In case of shortage of raw materials or uncontrollable manpower (such as transportation safety, weather, disasters and other factors), Party A shall notify Party B in advance;
2. Quality requirements: subject to the samples of Party A's exhibition hall. The quality standard agreed by both parties shall prevail.
4. Installation Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Verb (abbreviation for verb) installation and acceptance
1. Party A shall design, manufacture and install according to the design scheme signed and confirmed by Party B;
2. Accessories such as sinks, electrical appliances and baskets purchased by Party B must be delivered to the work site on the day of installation, and Party A will be responsible for the installation. 80 yuan/set for installation of sink, 60 yuan/set for basket pulling, 50 yuan/set for range hood. For each additional electrical appliance installed, the installation fee will be charged, 30 yuan. After normal installation and debugging, Party A does not guarantee any problems in the later period. If the accessories have quality problems, Party A has the right to refuse to install them after explaining to Party B, and Party B needs to make an appointment for the second service in advance, with the specific time determined by Party A, and the additional cost is 100 yuan/time;
3. After the product is installed, the customer must accept it on the spot. After confirmation, the product enters the after-sales service procedure. If Party B fails to raise a written objection within three days because of not attending the on-site acceptance, Party A will consider it qualified.
Responsibility assumption of intransitive verbs
1. Party A shall design, manufacture and install according to Party B's requirements, and Party B shall actively cooperate with Party A. If Party B fails to reserve the position of accessories according to Party A's design arrangement, Party A shall not be responsible for delaying installation or affecting appearance;
2. Party A orders production according to the drawings confirmed and signed by Party B. If there are any problems, Party A is responsible for replacing them for Party B free of charge. If Party B changes the styles, materials and related accessories beyond the drawings, the economic losses caused thereby shall be borne by Party B..
3. Party A calls Party B three days in advance according to the contract installation date to confirm the installation conditions (kitchen ceiling, wall tiles, power supply, etc.). Are in place). After the installation date is determined, if the goods arrive at the site and cannot be installed normally because Party B's decoration is not in place, Party B shall make an appointment for the second on-site installation in advance, and the specific time shall be arranged by Party A, and all expenses arising from the second installation shall be borne by Party B;
4. The size of electrical appliances provided by Party B must be provided to Party A before manufacturing and signed by Party B.. If the dimension provided by Party B is wrong, which leads to the manufacturing error of Party A, all losses shall be borne by Party B;
5. Due to different materials of door panels and different weights of hanging cabinets, in principle, it is not allowed to bear more than 10- 15 kg. If the hanging cabinet comes loose and falls off due to overweight articles, Party A will not bear any losses;
7. Warranty service: From the date of acceptance by both parties, we will provide a 36-month warranty for cabinets and door panels, a lifetime warranty for hinge slide rails and a lifetime warranty for common countertops (see the warranty standard for after-sales service cards). See the additional clauses in the main contract for details. Any damage caused by the quality of Party A's products shall be compensated by Party A. If replacement is required, Party A shall be responsible for replacement according to the exchange value of the products. The maintenance service caused by Party B's improper use does not belong to the above warranty scope, and Party A will charge the material cost and labor cost.
Eight. External service: after the warranty period expires, Party A's maintenance center will provide users with paid lifelong maintenance service, and all the replaced parts will be provided at the cost price;
Nine. Liability for breach of contract: both parties shall strictly abide by the terms of this contract in good faith. If there are any problems or disputes, they should be settled through consultation first. If the observant party fails to perform the contract through negotiation, it has the right to terminate the contract, and all economic losses suffered by the defaulting party shall be borne by it.
X this contract is made in triplicate and shall come into effect after being signed or sealed by the representatives of both parties. Party A holds two copies and Party B holds one copy, all of which have legal effect.
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _:
Simple Cabinet Contract 2 Party A (dealer): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (orderer): _ _ _ _ _ _ _ _ _ _ _ _
According to the relevant provisions of the Contract Law of People's Republic of China (PRC), both parties reached the following agreement through consultation:
Article 1 Party B shall pay a deposit of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 2 Party A shall provide the design drawings within _ _ _ _ _ _ _ days after measuring the dimensions (if the renderings are needed, both parties shall negotiate). After Party B completes the kitchen foundation works (ceiling, wall and floor tiles, water and electricity layout) according to the design drawings issued by Party A, Party B shall notify Party A to retest and modify the drawings. The drawings signed and confirmed by Party A and Party B are final design drawings.
Article 3 Once the drawings are confirmed, they shall not be changed at will. If one party needs to make major changes to the determined design drawings, it must obtain the consent of the other party and be signed by both parties, and the cost will be increased or decreased according to the actual situation, and the installation time will be postponed accordingly.
Article 4 Payment Terms
After being signed by Party A and Party B, the following _ _ _ _ _ methods can be selected for payment:
(1) on _ _ _ _ _ _ _ _ _ _
(2) _ _ _% of the advance payment paid by Party B to Party A on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ After the final installation is completed, Party B shall conduct acceptance according to the design drawings signed and confirmed by both parties. After the acceptance, Party B shall pay off% of the balance of the payment, namely RMB Yuan only (according to the actual settlement size).
(3) Other ways: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 5 Time limit for delivery
Party A shall deliver the goods before _ _ _ _ _ _ _ _ _ _ _ _.
Article 6 Delivery, Installation and Quality Assurance
Party A shall bear the transportation fee and loading and unloading fee in _ _ _ _ _ _ _ _ _ _ (region), but the fees charged by the property management department to which Party B belongs shall be borne by Party B ... The products provided by Party A shall be guaranteed with quality assurance 1 year warranty and lifetime maintenance (material fee).
Article 7 Liability of both parties
(I) Party A's responsibilities
1. After Party B pays the deposit, if Party A fails to provide the design drawings within the agreed time, Party A shall double the deposit to Party B..
2. Party A shall process and manufacture in strict accordance with the design drawings determined by both parties. If the finished product does not conform to the contract due to Party A's reasons, Party A shall bear the responsibility. Commitment: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
3. If Party A delays the delivery, Party A shall pay _ _ _% of the total payment to Party B as liquidated damages for each day of delay, amounting to RMB.
(II) Party B's responsibilities
1. Party B shall complete the kitchen foundation works (ceiling, wall and floor tiles, water and electricity arrangement) by itself.
2. If Party A submits the design drawings, the deposit will not be refunded.
3. After Party B pays, Party A starts production. If Party B requests to return the goods, the payment will not be refunded as the loss of raw materials.
4. If Party B delays the payment, Party B shall bear _ _ _ _% of the total payment as penalty for each day of delay.
Article 8 When Party A and Party B are unable to perform or need to postpone the performance of this contract due to force majeure, they shall promptly notify each other and explain the reasons for the inability or need to postpone the performance.
Article 9 In case of any dispute during the execution of this contract, Party A and Party B shall settle it through consultation. If negotiation fails, the following _ _ _ _ _ method can be adopted:
1, submitted to _ _ _ _ Arbitration Commission for arbitration;
2. Bring a lawsuit to the people's court according to law.
Article 10 In case of any matters not covered in this contract, both parties shall negotiate and make supplementary provisions in this contract. All supplementary provisions have the same legal effect as this contract.
Article 11 This contract is made in duplicate, one for each party.
Party A: _ _ _ _ _ _ (seal) Party B: _ _ _ _ _ _ _ (seal)
Person in charge: _ _ _ _ _ _ (seal) Person in charge: _ _ _ _ _ _ (seal)
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _ _ _ _ Signing time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Simple Cabinet Contract 3 Party A:
Party B:
In order to enhance the supplier's sense of responsibility and maintain the normal performance of the purchase and sale contract, through friendly negotiation between the supplier and the supplier, and in accordance with the provisions of the Economic Contract Law, the following contract is agreed, and both parties are expected to abide by it.
I. Formulation of contents:
Contract amount (excluding tax); RMB (in words) eleven thousand nine hundred and seventy-five Yuan (in figures) 1 1975.00 Yuan (in words).
2. Production requirements:
Party A shall ensure the quality of products and make them in strict accordance with the materials, colors and schemes required in the design contract. If there is any change, both parties shall confirm through consultation that the production quality shall be implemented according to the enterprise standards of the same industry.
3. Delivery and payment methods:
1. When signing this contract, Party B shall pay Party A 30% of the total contract amount as an advance payment, namely RMB.
2. Before Party A completes the delivery, Party B shall pay 60% of the second installment, namely RMB. Free delivery downtown.
3. The remaining amount of cabinets is 10%, that is, RMB. Please pay the balance as soon as possible after the installation is completed (no objection within three days is the contract).
4. Installation time: Party B shall install the tiles within 20 days after confirming the design drawings. If the plan changes or the installation is not urgent or the conditions are not mature, the installation time will be postponed.
This contract will take effect immediately after signing, and both parties will strictly abide by it. If the contract is terminated unilaterally, 30% of the total losses of both parties must be compensated.
6. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature by both parties.
7. Party B shall strictly abide by the payment terms. If the overdue period is more than 30 days, Party A has the right to demand Party B to collect 0.5% of the overdue fine as compensation.
8. Other supplements:
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Simple Cabinet Contract 4 Party A: _ _ _ _ _ _
Party B: _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, on the basis of equality, voluntariness, fairness, honesty and credit, the Buyer and the Seller have reached the following agreement on the purchase and sale of building materials:
Article 1 Basic information on purchasing building materials:
Article 2 Quality standard: National standard for the limit of harmful substances in interior decoration materials.
Article 3 Design:
(1) The seller needs to carry out field measurement.
(2) The seller's design scheme, after being signed and confirmed by the buyer, is an annex to this contract and has the same legal effect as this contract;
(3) After the design scheme is determined, it shall not be changed unilaterally without authorization, otherwise the responsibility and expenses caused by the change scheme shall be borne by the changing party.
Article 4 Delivery:
The mode of delivery is (delivery by the seller/delivery by the buyer) _ _ _ _ _ _ _ _ _;
Delivery time: _ _ _ _ _ _ _;
Delivery place: _ _ _ _ _ _.
Article 5 Installation: The installation method is (seller's installation/buyer's own installation); If the seller chooses to install, the installation standard is _ _ _ _ _ _ _ _ installation.
Article 6 Acceptance: If the specifications and colors of the cabinets are inconsistent with the agreement or there are other surface defects, the buyer shall raise an objection on the spot at the time of delivery, and the seller will unconditionally replace or supplement the objection after verification; If the seller is selected for installation, both parties shall * * * accept the installation quality within _ _ days after the installation is completed. If the acceptance does not meet the agreed installation standards, the seller shall unconditionally rework.
Article 7 Payment Method and Time: Both parties agree to pay the price by the first method.
When signing this contract, the buyer shall pay an advance payment of _ _ _ _ _ _ _ _ _ _ _ _.
Article 8 Liability for breach of contract
(1) Seller's liability for breach of contract:
1. For the quality problem of cabinets, if the country has three guarantees, it shall be implemented according to three guarantees; The warranty period without three guarantees stipulated by the state is _ _ _ years, and the seller is responsible for free maintenance. However, if it fails to meet the national mandatory standards or the quality standards agreed in this contract after being tested by a professional testing institution, the seller shall unconditionally exchange or return the goods or compensate the buyer for the losses incurred;
2. If the seller delays the delivery, it shall pay _ _ _ _ _% of the delayed delivery price to the buyer as liquidated damages every day; If the delivery is overdue for more than _ _ _ days, the buyer has the right to terminate the contract in addition to paying the liquidated damages, and the advance payment or price collected by the seller shall be returned in full.
(2) the buyer's liability for breach of contract:
1. If the buyer delays the delivery, it shall pay _ _ _ _ _% of the delayed part price to the seller as liquidated damages every day;
2. If the buyer unilaterally terminates the contract without justifiable reasons, it shall compensate the losses caused to the seller.
Article 9 Dispute Resolution: In case of any dispute arising from this contract, both parties shall settle it through consultation, or apply to the market organizer or consumer association for mediation, or complain to the administrative organ; If no settlement can be reached through negotiation, mediation or appeal, a lawsuit shall be brought to the people's court of _ _ _ _ _, or arbitration shall be applied according to the arbitration clause or arbitration agreement reached separately.
Article 10 Other agreed matters
Article 11 If the amendments or supplements to this contract unreasonably reduce or exempt the responsibilities of the seller, this contract shall still prevail.
Buyer (seal): _ _ _ _ Seller (seal): _ _ _ _ _ _
Address: _ _ _ _ _ _ Address: _ _ _ _ _ _ _
Tel: _ _ _ _ _ Tel: _ _ _ _ _ _
Authorized Agent: _ _ _ _ _ Authorized Agent: _ _ _ _ _ _
Signing time: _ _ _ _ _ Signing place: _ _ _ _ _ _
Simple Cabinet Contract 5 Party A (Owner):
Unit name:
Address:
Contact telephone number:
Party B (employee):
Name:
Gender:
ID number:
Home address:
Contact telephone number:
In view of the work needs of Party A, Party B is engaged in _ _ _ _ _ _ _ _ _
Rule number one. articles of agreement
The term of this agreement is _ _ _ _ _. This agreement will take effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 2. Contents and requirements of labor services
1. Party A arranges Party B to work in the post of _ _ _ _ _ _ _ _ _ (type of work). In general, Party B must complete the production (work) tasks, and the specific production (work) tasks are: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
2. Work place: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 3. Rights and obligations of both parties
1. Party B promises that according to Party B's current health condition, it can provide labor services for Party A as agreed in this contract and is willing to undertake the agreed labor services.
2. Party A entrusts Party B to undertake the work according to the business needs.
3. The working hours of Party B shall be determined according to the needs of Party A. ..
4. Party B shall abide by Party A's rules and regulations, meet Party A's requirements and standards, and accept Party A's performance appraisal.
5. Party B shall not provide or disclose Party A's business secrets to any third party in the course of providing services to Party A..
6. Party A shall pay remuneration to Party B according to the services provided by Party B. ..
7. All social labor insurance expenses of Party B shall be paid by Party B itself. Party A shall withhold and remit Party B's personal income tax according to law.
Article 4. Standard, method and time for Party A to pay Party B's service fee.
1, the service charge is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Payment method of service fee: on _ _ _ _ day of each month, Party A will remit the money to Party B's bank account (bank: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Account number: _ _ _ _ _ _ _ _ _ _ _ _ _).
Article 5, Work Discipline and Rules and Regulations
1. Party B shall abide by Party A's rules and regulations, obey Party A's leadership, management and command, complete work tasks on time, and keep Party A's business secrets.
2. If Party B violates the work discipline, Party A may give corresponding disciplinary punishment and economic punishment according to the rules and regulations of the unit until the Contract is dissolved.
3. Under any of the following circumstances, if Party A dissolves Party B's labor contract according to laws or company regulations, Party B shall pay compensation to Party A according to the labor contract:
(1) Party B has seriously violated the rules and regulations of the employing unit.
(2) Party B seriously neglects his duty and engages in malpractices for selfish ends, thus causing great damage to the employing unit.
(3) Party B is investigated for criminal responsibility according to law.
Article 6 Termination and rescission of the contract
1. If both parties fail to renew this contract after its expiration, this contract will be automatically terminated. Both parties shall handle the handover procedures in time.
2. Party A has the right to terminate this contract at any time according to business needs and Party B's performance. Party A shall not pay any compensation to Party B except the labor remuneration payable.
3. If Party B needs to terminate this contract in advance, it shall notify Party A _ _ _ days in advance, or compensate Party A for _ _ _ _ yuan instead of notice.
4. After the termination or dissolution of this contract, both parties shall handle the handover procedures in time.
Article 7. responsibility for breach of contract
1. If Party A fails to pay the labor remuneration to Party B on the date agreed in this contract, it shall pay liquidated damages to Party B at _ _ _% of the overdue amount for each day.
2. In the process of providing labor services, if Party B intentionally or negligently causes losses to Party A, it shall compensate Party A according to the actual loss amount.
Article 8. Dispute resolution method
Labor disputes arising from the performance of this contract can be settled by both parties through consultation. If negotiation fails, a lawsuit may be brought to the people's court of _ _ _ _ _ _ _ _.
Article 9, Supplementary Provisions
1. The Labor Contract is in the form of _ _ _ _ _ _ _ _.
2. This contract shall come into effect as of the date of signature by both parties.
Party A: (signature and seal)
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: (signature)
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Simple Cabinet Contract 6 is concluded by (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Contractor (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
According to People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Product Quality Law and other relevant laws and regulations, Party A and Party B have reached the following agreement on the basis of voluntariness, equality, fairness, honesty and credit:
Article 1 Name, quantity and price
I. Product name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Cabinet origin: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _; Total price: RMB _ _ _ _ _.
Two. For details of the quantity and unit price of Party A's customized cabinets and supporting products, please refer to Annex I "Price List", and for details of its design drawings, please refer to Annex II "Design Drawings".
Article 2 Quality standards
According to the following _ _ _ _ _ _ method:
The first is to implement the current national standards.
Second, _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 3 Mode of payment
The contract price shall be paid in the following ways:
1. Party A shall pay the full price to Party B before _ _ _ _ _.
Second, _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 4 Delivery and Installation
1. The cabinets ordered in this contract shall be delivered in the following _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _:
1. Party B shall deliver the cabinet to the place designated by Party A on _ _ _ _ _. The freight of _ _ _ _ _ _ _ Yuan shall be borne by _ _ _ _ _ _ _ _ _ _;
2. Party A arrives at _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
2. Party B shall complete the installation of the cabinet within _ _ _ _ _ days after the cabinet is delivered; After the cabinet is installed, the countertop installation shall be carried out within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The time from the delivery date agreed in this contract to the completion of installation shall not exceed _ _ _ _ _ _ _ _ _.
Article 5 Acceptance
1. Party A shall, within _ _ _ _ _ days after the cabinet installation is completed, check and accept the installed cabinet together with Party B's personnel.
2. If there is any quality objection, both parties agree to entrust _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 6 Rights and obligations of both parties
1. Party A's kitchen shall meet the following installation conditions (attached pages are available): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Party A shall provide the wiring diagram of kitchen water and electricity installation before the cabinet installation, and clearly mark the hidden wires and pipes in the wall.
3. All kitchen equipment and functional parts related to cabinet installation purchased by Party A shall be present before installation, so that Party B can locate and excavate.
4. Where Party B provides kitchen equipment and functional parts, Party B shall be responsible for installing them at the positions shown in the drawings, but Party A shall be responsible for connecting electricity, gas and water.
5. After the cabinet installation and acceptance, Party B shall provide Party A with invoices, product certificates, instructions and warranty cards.
6. The warranty period of this cabinet product is _ _ _ _ _ _ years, counting from the date of acceptance.
Article 7 Liability for breach of contract
1. In case of overdue payment, Party A shall pay _ _ _ _ _% of the overdue price to the other party as liquidated damages for each day overdue.
2. If Party B fails to complete the project on schedule, Party B shall pay liquidated damages to the other party at _ _ _% of the total contract price for each day overdue.
3. If the quality of cabinet products does not conform to the provisions of this contract, Party B shall rework or replace them free of charge. If the completion is delayed due to rework or replacement, Party B shall be liable for breach of contract. If Party B still fails to meet the agreed quality standards after rework or replacement, Party A has the right to terminate the contract and require Party B to bear the corresponding compensation responsibilities.
4. If Party B delays the delivery and installation due to Party A's reasons, and the completion date of delivery and installation is postponed, Party A shall compensate Party B for the losses caused thereby.
Party A: (signature and seal)
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: (signature)
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _