In today's society, people pay more and more attention to contracts, which is inseparable from many occasions. A contract can urge both parties to exercise their rights correctly and strictly perform their obligations. So what are the common contracts? The following are eight construction contracts that I have compiled for you, for reference only. Let's have a look.
Construction Contract 1 Party A: Zhangda Primary School in XX Town
Legal representative: XXX
Party B: Unity Group of Xinjian Village in XX Town
Legal Representative: XX
Through negotiation between Party A and Party B, and following the principles of equality, voluntariness, fairness and good faith, Party A contracted the school reservoir to Party B for new construction. In order to clarify the rights and obligations of both parties, this contract is hereby signed, and both parties are expected to abide by it.
I. Project name and place of implementation
Project Name: Reservoir Construction
Construction site: XX primary school campus
Second, the way of contracting: the contractor does not package materials.
3. The reservoir is built according to the topography, and the project price is 12000 yuan (65438 yuan +02000.00 yuan).
Four. Duration: 20xx years165438+1October 30th to 65438+February 65438+May.
Five, construction quality and material requirements:
1. Party B shall build a 50 cubic meter reservoir according to Party A's requirements. Quality requirements: the height is basically the same as that of the school playground; The thickness of the pool wall is not less than 30 cm, the bottom of the pool must be poured with underwater concrete (20 cm thick), and the top plate must be vibrated and the pool wall must be painted. Excellent waterproof quality, must meet the national anti-leakage test standards.
2. Considering the large span of the pool roof, it is necessary to pour beams when pouring the roof, and at the same time build piers under the intersection of beams to resist the roof. There should be no leakage or water leakage. The acceptance of the pool requires a one-month water storage inspection. After the completion of the reservoir, there are quality problems such as leakage, and Party B must repair them, otherwise 30% of the total project amount will be deducted.
3. Party B must install the drain pipe and outlet pipe of the cleaning pool and connect the pipe rack to the student canteen. Meanwhile, bury the pipeline. Party A is responsible for pipeline backfilling.
4. The entrance and exit of 70cm×70cm should be reserved at the top of the reservoir. The cover plates of reservoir and gate valve chamber are poured with cement mortar, and two movable cover plates are poured, with the steel bar density of 5× 5 ㎝. .
5. Party B must use earth and stone to tamp all around the masonry. The top plate of the pool is connected with the original hardening place.
Payment method of intransitive verbs:
After the completion of this project, 70% of the total project amount will be paid after the project is accepted, and the reimbursement will be based on the legal and valid tax invoice. The warranty period of the project is one year. In case of water leakage or water leakage (except natural disasters) within one year, Party B shall be responsible for handling it, and the warranty period shall be extended; After the warranty period expires, if there are no quality problems, Party A shall pay the remaining project funds in full.
7. If both parties breach the contract, they will be fined 5000 yuan. Eight, production safety and others
1, the contractor must carry out the construction according to the specifications and take full responsibility for the construction safety.
2, construction waste before the project completion acceptance, must be cleaned up.
3. Party B's construction must obey the supervision of Party A and relevant departments, and the next working procedure can only be carried out after each working procedure is completed and signed by the person in charge of Party A, otherwise Party A has the right to order it to stop working, and all losses caused thereby shall be borne by the construction unit. In case of quality problems and potential safety hazards, Party B will bear the responsibilities in accordance with relevant national regulations.
4. During the construction period, Party A only provides materials and water, and does not provide any construction tools. Party A shall prepare the required materials in advance and shall not delay Party B's time. (Except for special circumstances: transportation, materials, irresistible natural factors, etc. ).
5. Other matters not covered and disputes arising during the execution of the contract can be negotiated to sign a supplementary contract. The supplementary agreement has the same legal effect as this agreement.
Nine. This contract shall come into effect as of the date of signature and seal, in triplicate, one for each party and one for reimbursement.
Employer (Seal): Zhangda Primary School, Shishi Town, XX County.
Representative of Party A:
Contractor (signature and seal):
Representative of Party B
20xx165438+1October 30th
Part II of the Construction Contract Employer: zhijin county Nayong Primary School
Address: Aiguo Village, Nayong Town
Contractor Party B: Li Yong
Id number: 522426 19770429XXXX
Address: No.702 Huahua Road, Chengguan Town, zhijin county.
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement on construction matters.
I. Overview of the Project
Project Name: zhijin county Nayong Primary School Toilet Construction
Project location: behind the teaching building of Nayong Primary School in zhijin county.
Toilet structure: this project is a brick-concrete structure with a building area of 100 square meter. There are 18 squatting positions on the second floor and 20 squatting positions on the second floor. The interior wall of the bathroom is tiled to the top, the floor, bathroom and partition wall are tiled, and the ceiling is scraped with porcelain powder. Water, electricity, water tank (aluminum) and pipeline are all installed, and another 10 cubic meter three-room septic tank (not counting square meters) will be built. The unit price is 1680 yuan/m2, totaling168,000.00 yuan. (in words: one hundred and sixty-eight thousand yuan only).
Second, the safety requirements:
During the project, Party B must be present to supervise and take various safety measures. During the construction, Party B shall take full responsibility for the accidents caused by improper operation.
Three. terms of payment
When Party B enters the site, it shall pay the cost of engineering materials by itself. After completion, except for the warranty payment of 65,438+00,000 yuan (ten thousand yuan only), after the warranty period expires for one year, if there is no quality problem, Party A shall pay Party B the warranty payment of .. 10/00000 yuan (one hundred thousand yuan only).
Fourth, engineering materials and quality.
1. Party B shall be fully responsible for all losses caused by uneven upper and lower surfaces, movable beams, abutment beams, columns, door and window covers, stairs, etc.
2. Party B must guarantee the quality of building materials and projects. The materials used must meet the construction standards of the Engineering Office of the County Education Bureau.
V. Term of the Contract
Commencement date: July 26th, 2 0XX, completion date: September 60th, 2 0XX, 1, and total calendar days of the contract period: 36 days.
Verb (abbreviation of verb) liability for breach of contract
If one party breaches the above contract, the breaching party shall pay the other party a penalty of RMB 65,438+00,000 (ten thousand yuan only).
6. This contract is made in duplicate. Party A and Party B each hold one copy, which shall take effect from the date of signature by both parties and have the same legal effect.
Party A (signature): Party B (signature):
July 25th, 0xx.
Article 3 of the Construction Contract Party A:
Party B:
Party A built a multi-storey house with brick-concrete structure in the yard of the old house, and contracted it out to Party B without materials. In order to clarify the rights, obligations and projects of both parties, the following agreement is reached through negotiation:
1. Party A is responsible for the three links, one leveling and the surrounding relations.
2. Party A shall be responsible for all materials needed for the building.
3. Party A and Party B must carry out the construction according to the drawings. Any change must be agreed by both parties.
4. Party A shall be responsible for the temperature below 0.00, including the laying of the first floor precast slab.
Verb (abbreviation of verb) Party A is responsible for the secondary transportation of each floor of precast slab.
Scope of intransitive verb contract
1, dining board on the first floor, dining board on the second floor, dining board on the third floor, dining board on the fourth floor and dining board on the fifth floor. Second,
The third and fourth floors are paved with prefabricated panels, the fourth floor is poured with concrete, and the fifth floor is tiled.
2. Cushions and shingles shall be installed by Party B, and Party B shall be responsible for sending personnel to assist Party A in laying shingles on the roof.
3. Exterior wall facade tiles, tiles beside the gutter, indoor living room tiles, kitchen and bathroom wall tiles, floor tiles. The rest is common ground, the stairs are common ground, and the exterior wall is smooth and smooth with tripartite mortar.
4, water and electricity installation
The toilet is equipped with a bedpan, a water supply pipe, a water valve and a water nozzle. The kitchen is equipped with water supply pipes and nozzles. External wall water supply pipe and drainage pipe. (Electric) The stairwell is switched on the first floor with 1, the living room with two plugs 1, the room with 1, the kitchen with two plugs 1, and the bathroom with 1. (excluding lighting)
5. Party B shall be responsible for scaffolding, supports, templates and machinery in the drawings.
Seven. Nature of contract
1. Party A contracts to Party B in the form of RMB per square meter.
2. The materials should be placed at a place not more than 100 meters away from the construction site. If the limit is exceeded, the materials needed for construction shall not be in short supply according to the calculation of two-way transportation. If it is short-circuited, it should be regarded as shutdown.
Eight, quality requirements
1, brick masonry should be flat, straight and full of mortar. Internal and external painting must be smooth and flat, and must be qualified. Doors, windows and holes are not reserved according to the anchor size, and Party B shall be responsible for any problems found.
2. (excluding "888" paint), which is not within the scope of the recipient, belongs to the ancillary works, including septic tanks.
Nine, safety accidents
1. During the construction process, Party B shall prohibit the construction personnel from operating and constructing illegally. During the construction period, Party A and Party B shall bear different degrees of responsibilities in case of industrial accidents of Party B's operators.
X. receiving method
1, the receiver is subject to the external wall, with half skylight, half price, all balconies and all windows.
XI。 terms of payment
65438+
Twelve. Others:
If there are any matters not covered in this contract, Party A and Party B may sign a supplementary agreement through consultation.
This contract is made in duplicate, and both parties are expected to abide by it. It will take effect as of the date of signature.
Party A: Party B:
date month year
Article 4 of the Construction Contract Party A: Hotel
Party B: Travel Agency
Based on the principle of equality and mutual benefit, the two sides reached the following agreement on the accommodation of tour groups through consultation:
1. Party A's room rate for receiving Party B's team (groups with more than 65,438+00 people): during the peak season (4,5,6,7,8,9,65,438+00,65,438+0), the room rate for foreign guests is USD 35 per day. In the off-season (12, 1, 2, 3), foreign guests charge $28 per room/day, and domestic guests charge 140 yuan. Party B's escort room will be charged at half price, and if the team has a natural single room, it will be charged at full price, and there is no extra bed in the room.
Two. Meal standard for Party A's reception of Party B's team (10 group):
F: Breakfast: Dinner: (excluding drinks)
Domestic guests: breakfast: 10 yuan/person/day dinner: 18 yuan, (excluding drinks).
3./kloc-groups with less than 0/0 people are received as individual guests, and foreign guests are received at $60 per day in the peak season; In the off-season, it's $45 a day. All domestic guests will enjoy a 20% discount at the counter price.
4. Check-out: Check-out within 24 hours before the team arrives, and one day's room charge is required; It takes half a day to check out within 24 to 48 hours. In case of irresistible reasons such as natural disasters, both parties shall settle them through consultation.
Verb (abbreviation of verb) settlement method: 1 month 1 day, and settle the accounts of last month before the 5th of each month.
Intransitive verbs If there are any matters not covered in this agreement during the cooperation, both parties shall settle them through negotiation.
7. This Agreement shall be made in duplicate, one for each party, and shall come into force after being signed.
Signature of Party A and Party B:
Year, month, sun, moon, sun.
Article 5 of the Construction Contract Party A: (hereinafter referred to as Party B)
Party B: (hereinafter referred to as Party B)
According to (Economic Contract Law of the People's Republic of China) and (Regulations on Construction and Installation Project Contracts). According to the specific conditions of this project, Party A and Party B have reached the following agreement through friendly negotiation:
I. Overview of the Project
1. Project Address Name: Group 8, wuli village, Gaoba Town, Liangzhou District, Breeding Greenhouse Construction Project.
2. Project content: commencement and completion date, enclosure construction of breeding shed. The construction of this project is required by Party A. Commencement date () and completion date ().
3. Contract price: the enclosure wall of the breeding shed is 22 meters long, 16 meters wide and 3.3 meters high, and the foundation 1 meter. Concrete pouring is adopted, and the wall is built with 24X20X40 cement bricks, with a total length of 22+22+16+65438 = 76m.
4. All projects should be outsourced, not including food and accommodation, and the unit cost should be agreed at one time. During the construction period, Party B shall bear the change of project cost caused by the adjustment or increase or decrease of personnel salary. Party A does not increase the project cost.
Two. Party A's work
1. When the construction site has the conditions for commencement and completion, Party B requires Party A to connect the water and electricity roads before the planned commencement to ensure the smooth progress of the construction, and the construction water and electricity expenses shall be borne by Party A..
2. Party B shall ensure the progress of the project according to the requirements of the project, and be responsible for the safe construction during the construction period, and provide safety education to the construction personnel to prevent all accidents. In case of casualties. All responsibilities shall be borne by Party B, and Party A shall not bear any responsibilities.
3. Party A requires the materials on the construction site to be neatly stacked. After the project is completed, Party B shall be responsible for cleaning up the site, so as to clean up the site after the project is completed. Before delivery, Party B has the responsibility to protect the completed project. If any damage occurs during the protection period, Party B shall be responsible for repairing it at its own expense.
4. Inspection and rework: Party B shall carefully organize the construction according to the design requirements and construction specifications, and accept the supervision and inspection of Party A's representative at any time. If the inspection finds that it does not meet the requirements, Party B shall actively organize rework, and all expenses for rework shall be borne by Party B. ..
Third, the project payment
1. Before the project starts, Party A shall pay () yuan to Party B, and then pay () yuan when the project reaches 50%. After the project is completed and accepted, the remaining project payment shall be paid within () days.
2. If Party A fails to pay on time, it shall bear interest according to the bank loan interest rate and bear the liability for breach of contract according to law. If Party B fails to complete the project on schedule, Party B shall pay Party A a penalty of 5% of the total project price for each day of delay.
Fourth, quality assurance:
1. The quality guarantee period is () years. During the quality guarantee period, if there is any quality problem, Party B shall actively organize rectification, and all expenses shall be borne by Party B. In case of any dispute, both parties shall settle it through negotiation. If negotiation fails, the municipal construction and management department shall mediate or arbitrate by the court.
This contract shall come into effect after it is signed. After the completion acceptance, after Party B delivers the project to Party A, all other terms are terminated except the relevant terms.
This contract shall come into effect as of the date of signing, in duplicate, with each party holding one copy.
Party A (signature):
Party B (signature):
date month year
Article 6 of the Construction Contract: Employer: (hereinafter referred to as Party A) Legal Representative: Position:
Contractor: (hereinafter referred to as Party B) Legal Representative: Position:
In order to ensure that the project quality meets the requirements of national industry standards, give full play to the due benefits of the project, ensure the normal construction order of the project, and ensure the reasonable construction period and cost, according to the principles of the People's Republic of China (PRC) Contract Law and the actual situation of the project, both parties make the following clauses through consultation to restrain their actions.
I. Overview of the Project
1. Project name: to Duan, to Duan highway pavement reconstruction project contract section, project contract pile number:
2. Project content: See the bill of quantities for details, and Party A will notify the increased (or decreased) projects and quantities in writing.
3. Commencement date: year month day; Completion date: year month day; The total construction period is 10 days.
4. Quality grade: excellent.
5. Total contract price: RMB: (in figures: RMB)
Party B shall carry out the budget contract for this project, and it shall not be changed during the construction process except for the increased (or decreased) engineering projects or quantities notified by Party A in writing.
2. The documents constituting the contract are a whole, including
1. The agreed terms of this contract;
2. Construction organization plan;
3 industry standards and technical specifications stipulated by the Ministry of Communications;
4. Special technical terms issued by Party A;
5. Bill of quantities and design documents;
6. Relevant documents and instructions issued by Party A. ..
3. Without the consent of Party A, Party B shall not transfer this contract or any part thereof to other units or individuals. The failure of the project manager, technical director, construction personnel and quality inspection safety officer in the bid-winning notice to stick to the site is also regarded as subcontracting. If subcontracting is found, Party A has the right to regard it as a breach of contract and force it to leave. All expenses arising therefrom, including the construction part of the project (personnel, materials, equipment expenses, project losses and all management expenses arising therefrom), shall be borne by Party B. ..
Four, all materials, equipment and construction technology
1. It belongs to the corresponding category stipulated in the contract. In order to inspect, measure or inspect materials or equipment, Party B shall inspect them according to the requirements of the corresponding specifications of the Ministry of Communications before using them, and submit the inspection results to the supervisor and Party A, and they can only be used in the construction site after inspection meets the requirements, and the expenses shall be borne by Party B.. ..
2. Within the specified time, Party B shall remove any materials or equipment that are confirmed by Party A and the supervisor as not conforming to the specifications from the construction site and replace them with qualified materials and equipment.
3. Although inspection or payment has been made before, when Party A and the supervisors find that the materials, equipment or construction technology of their construction project are not up to standard, Party B shall dismantle the project and completely redo it, and the expenses shall be borne by Party B. ..
4. After the completion of this contract, Party B shall submit four complete sets of handover data to Party A within 15 days.
V. Construction period of the project
1. If Party B has no reason to extend the construction period and Party A thinks that the construction progress is too slow to be completed as scheduled, Party A shall notify Party B in writing. Party B shall immediately take remedial measures to remedy the situation, so as to speed up the construction progress and complete the project within the planned time. In this regard, Party B has no right to ask Party A to pay any extra fees. If Party B refuses to accept Party A's instructions to speed up the progress of the project, or Party B stops work for more than 5 days without the written consent of Party A and Party B, or Party B still fails to catch up with the scheduled progress of the project after taking certain remedial measures, it will be difficult to complete the project within the contract period, and Party A has the right to designate subcontractors or change contractors for all or part of the unfinished projects of Party B..
2. The project mentioned in the preceding paragraph has affected the construction period for various reasons, and corresponding measures must be taken in the next project to shorten the construction period on the premise of ensuring the quality of the project. In any case, the completion time of lime-fly ash macadam base and asphalt surface treatment pavement must be before.
3. If Party B fails to complete the construction of this contract within the specified time, Party B shall pay liquidated damages to Party A ... The default time shall be calculated from the second day of the specified completion time of a single project, and the liquidated damages shall be calculated at RMB/day, with the maximum amount of RMB; Reward RMB/day one day in advance, and the maximum bonus is RMB.
4. If Party B causes the extension of the construction period due to irresistible factors such as natural factors and social factors, Party B shall report to Party A in writing in advance, and Party A shall confirm the extension time of the construction period according to the actual situation, and the extension time of the project confirmed by Party A is a reasonable effective time of the construction period.
Coverage and shielding of intransitive verb items
Without the approval of Party A and site supervisor, no project shall be covered or covered. Party B shall ensure that the supervisors have enough time to detect or measure any project that needs to be covered and concealed. Whenever any part of the project or foundation has been or
When the inspection is ready, Party B shall notify the owner and the supervisor in writing in advance and agree on the inspection time. The supervisor shall participate in the inspection and measurement of the above-mentioned projects or foundations in time without undue delay. If the project supervisor fails to be present for inspection and measurement within the above-mentioned agreed 24 hours, Party B may inspect and truthfully make a self-inspection report, and then cover and cover it. The supervisor shall approve it afterwards.
Seven, the safety responsibility in the process of project implementation
During the construction, Party B must carry out the construction in strict accordance with the relevant national safety regulations. In case of safety accidents during construction, Party B shall bear compensation and administrative and criminal responsibilities.
8. Within 5 days after signing the contract with Party A, Party B shall provide Party A with a detailed project schedule according to Party A's overall construction arrangement, and the construction arrangement (including the arrangement in rainy season and busy farming season) and the explanation of construction scheme 9 shall be approved by Party A, and a commencement order shall be issued. If Party B fails to submit the project schedule, construction arrangement and construction scheme description in time, or the submitted materials do not meet the construction requirements, the commencement order of Party A cannot be issued, which will affect the construction period.
Nine. Party B shall strictly implement the terms of the contract agreed by both parties, carefully organize the construction, and complete the contract project and the repair of its defects on time. To this end, Party B shall provide all necessary supervision, management, labor, materials, equipment, construction equipment and others, and take full responsibility for the engineering quality of the construction site.
1. The project manager, technical director, site construction personnel and quality inspection safety officer shall be highway engineering technicians with long-term construction experience and approved by Party A. During the construction period, the above personnel must ensure the construction.
2. The engineering quality inspection and evaluation standards of each working procedure shall be implemented according to technical specifications. After each working procedure is completed, Party B shall check and sort out all the materials to meet the acceptance of Party A. ..
3. It is Party B's obligation to ensure the engineering quality. Party B shall do all the supervision and inspection work by itself and establish the corresponding self-inspection organization system. The contractor's self-inspection and test data must be signed by its self-inspection personnel and site supervision personnel before they can be used as data basis.
X the defects liability period of this contract is one year, which is within the defects liability period.
1. Party B shall complete the unfinished work specified in the handover certificate as soon as possible, and repair or repair the engineering defects at any time.
2. Within/0/5 days after the expiration of the defect liability period, Party B must repair, rebuild or repair the existing defects, diseases or other nonconformities according to the instructions issued by Party A on the inspection results before the expiration of the defect liability period.
3. The expenses for repairing the defects caused by the above reasons shall be borne by Party B. ..
XI. About the payment of project cost.
1. When signing this contract, Party B shall also submit a project quality deposit of RMB ten thousand Yuan only (in words), and the project quality deposit will be returned monthly with the construction progress of the successful bidder. When the medium-term measurement amount of the construction unit reaches or exceeds 10,000 yuan, the project quality deposit will be returned in full.
2. Time and amount of project payment: the contract project adopts monthly measurement method according to the actual progress of the project: interim measurement is carried out on the 25th of each month (10% of the project measurement amount is withheld as the project quality deposit). The final measurement shall be carried out when all projects are completed, accepted and delivered for use, and the accumulated project payment paid by the owner shall not be less than 50% of the total contract price; Before the expiration of the defect liability period, the owner has paid 90% of the total contract price; Withholding 10% of the project quality deposit shall be paid in one lump sum within 30 days after the expiration of the defect liability period, such as non-defective projects, defective projects and unfinished projects.
Twelve. This agreement shall come into force as of the date of signing. This agreement is made in duplicate, one for each party.
Party A (signature): Party B (signature):
Date of conclusion of the contract: year month day.
Article 7 of the Construction Contract Party A:
Party B:
Party A plans to build a brick and wood sheep shed in Xusan Bay. In order to clarify the contractual relationship between the two parties and protect the legitimate rights and interests of both parties, both parties agree to sign a contract through consultation, such as
During the contract period, it shall not be changed, and both parties are expected to comply with it.
I. Building area
Among them, the length, width and height of the sheephouse are meters, and the construction area is square meters.
Second, the contract price
Party A will contract the sheep shed to Party B at the price of RMB per square meter, with a total amount of RMB.
Three. rights and duties
1. Party A must provide all kinds of materials and water circuits needed for construction according to the construction requirements, so as to ensure that Party B can carry out the construction on time. No materials are prepared during the construction, and the expenses shall be borne by Party A. ..
2. Party B must complete the contracted project on time with good quality and quantity according to Party A's construction requirements, so as to achieve reasonable construction and reasonable materials, and shall not waste and misappropriate construction materials at will.
3. Party B must carry out the construction on the principle of safety first, and all accidents and expenses during the construction shall be borne by both parties.
Four. mode of payment
At the initial stage of construction, Party A shall pay Party B% of the contract price for living expenses, and the rest shall be paid in cash at one time after the completion of the project.
Verb (abbreviation of verb) construction period
This project started on June 6, 20 13 and was completed on June, 20 13. This contract has legal effect from the date of signing. Any party who breaches the contract shall submit it to the Legal Department for arbitration. This contract is made in duplicate, one for each party.
Party A: Party B:
Year, month, sun, moon, sun.
Article 8 of the Construction Contract Party A: Luodian County Bureau of Land and Resources
Party B: Deng Deping
1. Name of construction project: land and resources publicity archway (* * * 8)
2. Construction cost: The lump-sum price of each publicity archway in Qian Lu is RMB 3,997.00 (RMB:6397.00), and eight billboards are RMB 511,176.00 (RMB 51176.00).
Second, the construction period: 20xx, from August 20th to September 20th, with all the construction work completed within one month.
3. Construction site: Longping Town and towns in Robbie District (Longping, Gouting, Robbie, Camel, Russell, Luomu and Hongshui River). Among them, there are two Longping towns, one is located at the intersection of Duyun and Guiyang entering Luodian, one is located near the "Jiao Yan" liquefied gas station of the state-owned forest farm, and the other six are located in prominent positions in various township jurisdictions, subject to the negotiation between the two parties and local towns.
5. Architectural style and area. According to the document requirements of Qiannan Land and Resources Bureau, the publicity area of the building owner is 5m and the height is 3m. White kitchen and bathroom wall tiles and base wall tiles are pasted on the front, back, left, right and top surfaces, and the slogan that red paint cannot be changed is printed. The content of the slogan is subject to the document requirements of Qiannan Land and Resources Bureau. Bricks for main body and stone sand for footings shall be paid by Party A, and the freight shall be borne by Party B.. All other extra works, such as footings and foundations, should be included in the total budget.
The rights and obligations of Party A are intransitive verbs. Party A is responsible for cooperating with Party B in site selection.
Responsible for coordinating the land disputes at the project construction address and other practical problems encountered in the construction process to ensure the normal construction of Party B. ..
Seven. Party B's rights and obligations. Responsible for completing the archway construction project in accordance with the address and relevant villages and towns selected by both parties through consultation. Non-human factors shall not cause collapse, damage, brick falling, convex surface, depression, paint falling, etc. Due to quality problems.
Eight, the way of disbursement of funds. After the commencement of construction, Party A shall pay 25,000 yuan in advance to Party B, and the remaining 95% shall be paid by the construction project invoice and relevant acceptance materials after the project is fully accepted, and the remaining 5% shall be settled in one lump sum after there is no quality problem within one year.
Nine. Matters not covered in this contract shall be settled by both parties through consultation.
X this contract is made in duplicate, one for each party.
Party A (seal): Party B:
August 2, OXX1day.