In a society where people pay more and more attention to the law, the binding force of the contract on us is more and more non-negligible, and the signing of the contract is also one of the best ways to avoid disputes. Then how to draw up the contract? I think this makes us all very distressed, the following is my central air conditioning installation contract for you to organize, just for reference, I hope to be able to help you.
Central air conditioning installation contract 1Party A:
Party B:
According to the "Chinese People's **** and State Economic Contract Law" relevant provisions, by the A and B friendly consultation, reached a contract for the installation of equipment, the contents of which are as follows:
I. Project Overview:
Name of the project: Central air-conditioning system installation and commissioning
Project location:
Second, the scope of the contract:
The scope of this contract: the project central air-conditioning system project installation, commissioning, acceptance and maintenance.
Party B shall provide brand new unused installation equipment and materials, technical services and other matters required. In the performance of the contract, if Party B does not provide or does not meet the technical performance indicators in the design drawings, Party B shall take free salvage measures, and bear full responsibility. If Party A needs the technical requirements which are not presented in the contract documents, Party A has the right to issue a change notice, and Party B has the responsibility to meet Party A's change requirements with reasonable progress as well as the most favorable price.
Bidding documents and bidding documents as an annex to the contract, forming an integral part of this contract, Party A and Party B **** the same commitment to comply with.
Third, the contract cost:
The total cost of this contract is: ￥ yuan
RMB capitals: yuan
3.1 "contract price" refers to the project central air-conditioning system engineering, in addition to Party A supply central air-conditioning system equipment, except (Party A supply equipment see schedule). In addition to Party A's supply of central air-conditioning system equipment (see the attached table for Party A's supply of equipment), the contract price is quoted in RMB from the installation of equipment and
materials, installation and commissioning, supply of spare parts to the completion of the acceptance of the delivery of the use of the maintenance of which includes the cost of materials, packaging, transportation and miscellaneous expenses, loading and unloading, installation, commissioning, supply of spare parts until the acceptance of the delivery of the use of the cost of all the costs and the cost of maintenance during the maintenance period, and so on.
3.2 The contract price is a fixed price, including all additional costs due to price fluctuations in raw materials, labor costs or other conditions, except for price adjustments caused by Party A's increase or decrease in the volume of work.
3.3 The contract price includes the contract involved, provided by Party B and the installation and commissioning of equipment during the period of all the special tools, testing and the use of instruments, the cost of supplies, and Party B is responsible for the transportation into and out of the project site.
3.4 The contract price includes all the transportation, accommodation and food costs of Party B personnel to the site, Party A to assist the convenience of Party B personnel to live at the site, but the relevant costs by Party B at its own expense.
3.5 Unless otherwise specified, Party B's price shall include the execution and completion of the work described in the Contract Documents and all incidental work and expenses indispensable to the execution and completion of the work, whether or not they are stated in the Contract Documents and whether or not they could have been anticipated at the time of entering into the contract.
Party A (Official Seal): _________ Party B (Official Seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ _________ ____ _________ Day
Central air-conditioning installation contract 2Party A (purchaser):
Contact phone number:
Party B (supply and installation):
Contact phone number:
According to the "Chinese People's Republic of China *** and the State of the contract law" and other relevant laws and regulations, on the basis of equality and voluntariness, Party A and Party B on the installation of the central air-conditioning equipment of the Party B reached the following agreement. The following agreement:
Article A order and equipment specifications and quantity, as well as the project profile:
1, equipment (see the quotation table):
2, the installation project profile:
Project location:
Start date: XX year month and month
Completion date: XX year month and month
Article 2 When Party B's project materials enter the site, Party A confirms and designates the place where the goods are stacked (the place designated by Party A must be with safety guarantee), and the safety of the project materials shall be the responsibility of Party A and Party B*** together.
Article III product installation, commissioning, acceptance:
1, Party B is responsible for the installation and commissioning of central air conditioning equipment.
2, the installation quality standards in accordance with national norms and industry requirements, as well as Party B and the manufacturer to provide engineering installation design instructions. Party B notified Party A of acceptance on the day of completion of the project, Party A within three days of receiving the acceptance notice to organize personnel to accept the project, that the quality of the project and project content in line with the requirements of the two sides on behalf of the acceptance of the project (form) signed and stamped. Product installation program proposed by Party B and agreed to by Party A design drawings, selection program shall prevail; need to change the design, subject to the agreement of the two sides; involves the adjustment of the model, subject to confirmation by the two sides to negotiate.
Article IV Payment:
1, the contract price for the two sides of the contract works + negotiation price;
2, the total price of the contract works for the RMB ￥ yuan (Upper case: round round)
3, when the contract is signed, Party A to pay the Party B works deposit of RMB ￥ yuan;
Upper case: round (30% of the total price of the project);
4, Party A to pay the Party B, the project deposit of RMB ￥ yuan;
Upper case: round (30% of the total project price);
The contract is signed by Party B, Party A to pay the Party B to pay the Party B deposit of RMB ￥ yuan.
4, Party B engineering materials and equipment into the site, Party A acceptance signature to pay the second phase of the Party B project payment of RMB ￥ yuan, capital: round (60% of the total price of the project);
5, the rest of the money in the commissioning of the equipment is completed, the project is completed and acceptance of the balance of the payment (based on the date of the acceptance report), Party B has not paid the full amount of money before the material and the air-conditioning equipment belongs to the Party;
5, the remaining amount of money in the equipment commissioning is completed, project completion and acceptance of the balance (to acceptance report date), before the full payment of materials and air-conditioning equipment belongs to the Party. Party B notifies Party A of acceptance, Party A does not participate in the acceptance within one week without reason, as acceptance.
6, the above price does not include community management fees, including special drilling machine drilling costs, including equipment lifting costs.
Article V responsibilities of the two sides
I. Party B's responsibility:
1, the project site B responsible for the installation of the construction site is fully responsible for the work;
2, in addition to the negotiation, such as Party B delayed the delivery of the work, should pay liquidated damages to the Party, but the total amount of liquidated damages shall not exceed the total amount of the price of the ` 20%. If Party B fails to hand over the work after reaching this limit, Party A may consider terminating the contract, and Party B shall bear the loss caused to Party A as a result. Except for Party A's signature and approval.
3. If Party B delays the construction period without any reason, Party B shall pay to Party A 1‰ of the price of liquidated damages for every one day of delay, except for the reasons caused by Party A.
Second, Party A's responsibility:
1, the person in charge of the project site Party A is fully responsible for the installation of the construction site coordination and cooperation;
2, Party A is responsible for air conditioning inside and outside the machine power supply laying and construction of the outdoor unit base.
3, Party A is responsible for the construction of water and electricity expenses during the construction period and to assist in the construction of Party B's entry and exit certificates.
4. If Party A terminates the project in the middle of the construction period, it should pay 50% of the contract sum to Party B as liquidated damages.
5, Party A fails to pay the project payment according to the time specified in the contract, for each day late, Party A shall pay Party B 1‰ of the total amount of the contract, but the total amount of liquidated damages does not exceed 20% of the total amount of the contract. If Party A fails to pay after reaching this limit, within one month, Party B has the right to terminate the contract and recover the central air-conditioning equipment and ancillary materials, and Party A shall bear the economic loss of Party B, and Party B may also pursue Party A's relevant legal responsibility.
6, Party A should notify Party B in time if it needs to adjust the product model, and bear the costs of Party B's repeated transportation, storage, equipment price difference, material loss, etc.
7, Party B has the right to terminate the contract and recover the central air-conditioning equipment and ancillary materials.
7, the following reasons for the delay in the completion date, confirmed by Party A and Party B, the extension of the construction period accordingly:
(1) changes in the amount of work or design changes;
(2) force majeure;
(3) Party A did not pay the money and did not participate in the stage of acceptance and the stoppage of work;
(4) Party A agreed to the extension of the construction period. Other circumstances.
Article 6 product quality responsibility and after-sales service terms
1. From the date of acceptance, the project warranty period of one and a half years (i.e. 18 months).
Outside the warranty period due to product quality problems, then Party B charge the basic maintenance costs, replacement of damaged parts, according to the ex-factory price of the replacement parts charged.
2. After the end of the warranty period, Party B provides lifelong paid maintenance services for air conditioning users. Service content and mode, by the user and Party B separate voluntary contract to be determined.
Article VII due to the occurrence of force majeure factors resulting in the contract can not be normal fulfillment of the two sides to resolve the friendly negotiation.
Article VIII dispute resolution contract: the implementation of the contract dispute, the two sides to resolve friendly consultations. Consultation can not be resolved, either party may, in accordance with the law to the plaintiff's seat of the People's Court litigation.
Article IX of this contract shall enter into force on the date of signature and seal of both parties.
Article 10 submitted by Party B and confirmed by Party A of the project's design drawings and quotations program specification and other texts as an annex to this contract.
Article 11 of this contract, if there are other outstanding issues, by both parties **** with the consultation, to make additional provisions, additional provisions and this contract has the same effect.
Article 12 of the original contract in duplicate, A and B each party.
Article 13 of the contract annexes are part of the contract, and the contract has the same legal effect.
Party A: Party B:
Agent: Agent:
Tel: Tel:
Date: Date:
Central Air Conditioning Installation Contract 3Party A: Tel:
Party B: Tel:
Party A and Party B, in accordance with the relevant provisions of the "Contract Law" and through friendly consultation, the following terms.
First, the installation project: central air conditioning equipment
1, the installation location:
2, the structure of the house:
3, the installation content and price (see construction drawings and both sides to confirm the offer details)
Second, the installation time and warranty period:
1, the installation time: the interior synchronized and coordinated, shall not be improperly time and affect the party's decoration. Improper time and affect the Party A decoration project changes or progress.
2, warranty period: from the installation and commissioning of qualified free warranty for five years, lifelong maintenance.
Third, the central air conditioning brand and the total price
1, the installation brand: "Gree B series," the material requirements of the ancillary facilities, see the "central air conditioning equipment installation quotation"
2, the installation price:
3, this price is to ensure that the air conditioning normal operation of the final price.
Fourth, the payment method:
Fifth, the installation requirements:
1, the specific location of the installation: the location of the vents, wiring, etc. in accordance with the two sides to confirm the construction drawings, Party A, such as the temporary need to change the two sides separately agreed.
2, Party B installed air conditioning brand, the use of materials must be consistent with the quotation of the brand, specifications, models, quality, measurement standards, and in line with a variety of national safety regulations and industry norms.
Six, installation and acceptance:
1, based on the installation of construction drawings confirmed by the two sides, if there are changes, the two sides need to consult.
2, the use of brands, materials, models, etc. and quotation details in line with the use of the effect to achieve the indicators of the manual.
VII, liability for breach of contract:
1, Party B installation time must be coordinated with the progress of Party A decoration works, affecting the progress of Party A decoration works, etc., to bear the corresponding delay in the loss of Party A.
2, Party B installation time must be coordinated with the progress of Party A decoration works.
2, Party A late payment, daily by two thousandths of the total price of the project to pay Party B.
3, Party B installation time must be coordinated with the progress of Party A decoration project.
3, such as Party B in the installation of the use of counterfeit or shoddy brands, materials, Party A has the right to order Party B to remove and replace until it meets, and bear the corresponding losses.
4, the trial period, such as the occurrence of quality problems, thus giving party A decoration losses caused by party B.
VIII, this contract is not exhaustive consultation to solve the problem, this contract in triplicate, the two sides of an executive copy, the manufacturer holds a copy of the two sides to sign and enter into force.
IX, if the two sides due to the quality or cooling, heating effect of objections, disputes, through the authority to identify the standard solution.
Party A: Party B:
Legal representative: Legal representative:
Agent: Agent:
Phone: Phone:
Fax: Fax:
Date: Date:
Central Air Conditioning Installation Contract 4Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
According to the "Chinese People's **** and State Contract Law" and the provisions of relevant laws and regulations, the two sides on the basis of equality, voluntariness, friendly consensus, on the Zhuxi County Power Supply Bureau of the central air-conditioning project installation and procurement of related matters, to reach an agreement as follows:
I. Scope of the project: central air-conditioning equipment purchasing, construction, installation and commissioning of the Zhuxi County Power Supply Bureau.
Second, the project requirements: in accordance with the central air-conditioning contract signed by Party A and the owner of the installation requirements, in accordance with the design program will be determined by the central air-conditioning and end of the system configuration and installation in place.
Third, the cost of the project and the cost of payment:
1, the total cost of the project for the RMB: the above price does not include the host foundation, host power, the main pipeline of the steel frame of the use of fees.
2, after the signing of this agreement within three days of Party A to pay Party B full payment of the project, Party B into the construction.
3, Party B bank account:
Fourth, the quality of the project:
1, Party B must be strictly in accordance with the requirements of Party A construction schedule progress, if the work schedule is late due to the loss of Party A, the loss of the Party B bear the full amount.
2, Party B must use materials in line with national standards, for each batch of installation materials by the Party A technicians random inspection and acceptance of materials that do not meet the requirements of Party A has the right to require Party B to replace, and the resulting delay in the project and other losses borne by the Party B itself.
3, Party B must be in accordance with the installation specifications and process requirements of the construction, the installation process of the installation quality and process, Party A has the right to check the technical staff, does not meet the requirements of Party B must be unconditionally rectified and bear all the losses of missed work.
Fifth, equipment and engineering quotation list
Six, after-sales commitment
1, system warranty: the installation warranty period of 2 years, the warranty start time for the date of acceptance of the completion of the project began to calculate. Warranty period due to the quality of the installation failure, by Party B free of charge maintenance. If the failure is caused by Party A's improper operation or equipment operating environment, Party B will not undertake free maintenance. After the warranty period. Party A and Party B can be negotiated separately, maintenance matters.
2, the equipment from the date of shipment warranty of 2 years, if due to improper operation of Party A or equipment operating environment resulting in failure, Party B does not undertake free maintenance. After the warranty period. Party A and Party B can be negotiated separately, maintenance matters.
VII, this contract is not exhaustive, by Party A and Party B to negotiate a solution, consultation fails, can be resolved by litigation to the local people's court.
VIII, this contract is a four-part, A and B each two copies. Both sides signed and sealed to take effect!
Party A: Party B: Legal Representative: Legal Representative: Entrusted Agent: Entrusted Agent:
Signing Date: Monthly Date: Monthly Date
Central Air Conditioning Installation Contract 5Party A:
Party B:
According to the "Economic Contracts Act" and the "Construction and Installation Contract Contracts" of the relevant provisions of the contract, combined with this project, the situation of the two sides through careful negotiation, reached a consensus. The situation, the two sides carefully negotiated, reached the following agreement:
A project overview
1 ﹑ Project Name:
2 ﹑ Project Location:
3 ﹑ equipment supply and supply contracting scope
(1) This contract includes supermarkets, centralized air conditioning system supply, installation and debugging, air conditioning, see the design drawings.
(2) installation includes fan coiler installation, outdoor host installation, pipe connection, pipe insulation, system commissioning.
(3) The concrete foundation of the air conditioning outdoor unit will be made by Party A in advance according to the size parameters provided by Party B.
(4) The power supply of outdoor and indoor units will be laid in place by Party A. Party B will be responsible for the holes through the beams where air-conditioning pipelines pass through, and Party A will be responsible for the restoration work, and Party A will be responsible for the laying of the control line pipe, and Party B will be responsible for the connection of the power line and the outdoor and indoor units.
4, the duration: according to the requirements of Party A, combined with the actual situation on the site, subject to the date of Party B into the site, the construction period is set at 30 days in the event of the following circumstances, the construction period will be postponed.
(1) delay in the allocation of funds for the project.
(2) Delays in cross work and technical visas.
(3) Force majeure.
(4) Delays in construction period not caused by Party B.
5, the quality of the project: in accordance with GB - 50243 construction, acceptance.
Contract price
1, air-conditioning equipment and installation
No. Name Model and specifications Quantity Unit Unit price Remarks
1 refrigeration host and attached material installation cost of the unit
2 fan coil and attached material installation cost of the unit
Total
2, the mode of payment
(1) air-conditioning equipment payment
A Party A from the contract signed within three days after the payment of 30% of the total cost of the project prepayment.
B 40% of the total cost of goods to the site.
C Installation is completed within ten days after acceptance to pay 20%.
D after completion of a cooling season to pay 95% of the contract. (Leave 5% warranty deposit)
① Remaining 5% as warranty deposit is paid within seven days after two years.
(2) such as equipment, engineering changes, can be issued by the construction representative of Party A to Party B equipment, engineering change orders, and signed a separate change agreement as an attachment to this contract, and this contract has the same legal effect.
Third, completion and acceptance:
1, completion and acceptance and intermediate acceptance are based on the agreement between the two sides, the design and construction drawings, the relevant changes in visas and relevant construction specifications.
2, intermediate acceptance and approval of other construction documents, Party A should be completed within two days of Party B submitted information or reports to assist Party B **** with the completion of the project so as not to affect the follow-up work, late means that Party A has recognized.
Fourth, warranty:
1, Party B on its supply and construction of equipment and engineering within the scope of the warranty for two years without compensation.
2. The warranty period is calculated on the date of qualified installation and commissioning.
Fifth, the responsibility of both parties:
1, Party A's responsibility
(1) Party A should ensure that the construction site with construction conditions, to ensure that water, electricity and road three-way, to provide storage warehouses, Party B to bear the cost of electricity and water, Party A with the contents of the construction of the B side.
(2) Party A appointed as the site site representative, if there are changes in two days' written notice to Party B in advance.
(3) Party A site representative has the responsibility to coordinate the site cross work and other work matters.
2. Party B's responsibility
(1) According to the technical requirements of the contract, to provide brand new equipment, to ensure that the performance of all parts of the equipment is intact, in line with technical standards.
(2) Party B according to the construction drawings and related changes in the field visa quality and on schedule to complete the construction content.
(3) Party B appointed as site representatives, such as changes in two days' written notice to Party A.
(4) Party B to obey the Party's reasonable work arrangements.
Six, other:
1, if there is a dispute, the two sides in the principle of friendly consultation to resolve the consultation results in the form of "summary", as an attachment to the contract, and the contract has the same effect, the consultation fails to be in accordance with the Economic Contract Law and other relevant provisions.
2, the responsibility for breach of contract and loss according to the actual loss.
3. The construction drawings, changes and other technical documents recognized by Party A related to this contract shall have the same legal effect as the contract.
4, the tender as an annex to the contract has the same legal effect.
7, the contract in six copies, Party A retained four. Party B to retain two copies.
Party A (Chapter): Party B (Chapter): Party A's representative: Party B's representative:
Tel: Tel
Tel:
Tel:
Fax: Fax:
Central Air Conditioning Installation Contract 6Contracting unit: _________________________________ (hereinafter referred to as Party A)
< p> Contact number: _____________________ Unit address: _____________________ Representative of Party A: _________________________________Contracting unit: ___ ___ (hereinafter referred to as Party B)
Contact number: _____________________ Unit Address: _____________________ Party B's representative: _________________________________
According to the provisions of the Contract Law of the People's Republic of China*** and the State of China and other relevant laws and regulations, on the basis of equality and voluntariness , Party A and Party B reached the following agreement on Party B's installation of central air-conditioning equipment:
Article 1 Specification models and quantities of equipment ordered by Party A and installed by Party B, as well as the project overview:
1. Equipment:
Product name Specification model unit quantity
2. Installation project overview:
(1) Location and area of the project: ;
(2) project cost: ￥ yuan;
(3) start date: 20xx months;
(4) completion date: 20xx months;
(5) Payment: (1), cash (2), transfer check
Article B engineering materials into the field, confirmed by Party A and designated goods stacking location (Party A designated) The location must be a security guarantee), the safety of engineering materials by Party A and Party B **** the same responsibility. Party B installation and commissioning of central air-conditioning is completed, Party A site acceptance, and sign acceptance recognition; without Party A and Party B acceptance signature, materials, equipment shall not be used, installation.
Article III product installation, commissioning, acceptance:
1, Party B is responsible for the installation and commissioning of central air conditioning equipment.
A and B agreed:
(1), before the month of 20xx, Party B sent engineering and construction personnel to arrive at the site to start the installation of the construction;
(2), before the month of 20xx, to complete the preliminary concealed engineering and acceptance of the project;
(3), before the month of 20xx, to complete the installation of equipment and commissioning of systems Operation; all central air-conditioning project completion and acceptance, together with the completion of the decoration. Required materials are in place according to the time agreed upon by both parties.
2, installation quality standards according to national norms and industry requirements, as well as Party B and manufacturers to provide engineering installation design instructions. Party B notified Party A of acceptance on the day of completion of the project, Party A within three days of receipt of the acceptance notice to organize the acceptance of the project, that the quality of the project and the content of the project in line with the requirements of the representatives of the two sides in the acceptance of the project sheet (form) on the signature and seal. Party B is responsible for providing product qualification certificates, material qualification certificates, product warranty, daily running operation program description and fault consulting. Product installation program proposed by Party B and agreed to by Party A's design drawings, selection program shall prevail; need to change the design program, subject to the agreement of the two sides; involves the adjustment of the model, the contract should be signed to confirm the supplementary text.
Article IV price settlement and period:
1, the price of this contract for the two sides agreed to pay the installation works (fixed price);
2, the total price of this contract for the installation of the project for the RMB: ____________________ yuan (capitals:);
(1) after the signing of the contract, Party A pays Party B (the first installment of the project) RMB: ____________________ yuan (capitals:);
(1) after the signing of the contract, Party A pays Party B (the first installment of the project) RMB: ____________________ yuan (capitals:);
(1) after the signing of the contract, Party A pays Party B ( The first phase of the project payment) RMB (__50__% of the total contract amount) __________________ yuan (capitals:);
(2) Party B project materials (non-finished products) into the site, Party A acceptance signature, Party A within three days to pay Party B (the second phase of the project payment) RMB (__47__% of the total contract amount) __________________ yuan (capitals:);
(3) the final payment of the project (accounting for __3__% of the total amount of the contract) yuan (capitals: _______________________ yuan), equipment debugging is completed, the completion of the project after acceptance, Party A within three days to pay off. Party A has not paid the full amount before the material and air-conditioning equipment belongs to Party B.
3, the above price does not include community management fees, does not include special drilling machine drilling costs, does not include equipment lifting costs.
Article V Responsibility for breach of contract
I. Party B's responsibility:
1, the person in charge of the project site B is fully responsible for the installation of the construction site;
2, in addition to the provisions of the contract, if Party B did not hand over the time specified in the contract, for each day of late handover, Party B should be paid to Party A, the total amount of the price of the 1 ‰ of liquidated damages, but the total amount of liquidated damages shall not exceed 20% of the total amount of the price. The total amount of liquidated damages shall not exceed 20% of the total price. If Party B fails to deliver the work even after reaching this limit, Party A may consider terminating the contract, and Party B shall bear the losses caused by Party A as a result. Party B shall bear the losses caused by Party A. Except for Party A's signature and approval.
3. If Party B delays the construction period without any reason, Party B shall pay to Party A 1 per cent of the price for each day of delay, except for
the reasons caused by Party A.
4, due to the installation of non-quality requirements, resulting in responsibility and loss of Party B is responsible for.
Second, Party A's responsibility:
1, the person in charge of the project site Party A is fully responsible for the installation of the construction site;
2, before the start of construction _____ days, Party A should be for Party B to create conditions for the construction of the construction site, vacate the site, connected to the construction of water and electricity;
3, before the start of construction _____ days, Party A should be provided with Party B has been determined by the design of the plan and the installation of construction lists;
4, due to installation of the quality requirements, the responsibility and losses caused by Party B is responsible for. Installation and construction list;
4, Party A terminates the project in the middle of the contract, Party B should be reimbursed 50% of the contract amount of liquidated damages.
5, Party A fails to pay for the works according to the time specified in the contract, for each day late, Party A shall pay Party B 1‰ of the total contract sum as liquidated damages, but the total amount of liquidated damages shall not exceed 20% of the total contract sum. If Party A fails to pay after reaching this limit, Party B has the right to terminate the contract and recover the central air-conditioning equipment, and Party A shall bear the economic loss of Party B. Party B may also pursue Party A for the relevant legal responsibility.
5. If Party A needs to adjust the product model, it should notify Party B in time and bear the costs related to Party B's duplicate transportation, storage, equipment price difference, material loss, etc.
6.
6, the following reasons for the delay in the completion date, confirmed by Party A and Party B, the extension of the construction period accordingly:
(1) changes in the amount of work or design changes;
(2) force majeure;
(3) Party A did not pay the money and did not participate in the stage of acceptance and the stoppage of work;
(4) Party A agreed to the extension of the construction period. Other circumstances.
Article 6 Product quality responsibility and after-sales service terms
1. From the date of acceptance, the project warranty period is one year (provided by the Great Forest Forest Refrigeration).
Outside the warranty period due to product quality problems, then Party B charge the basic maintenance costs, replacement of damaged parts, according to the ex-factory price of the replaced parts.
2. After the end of the warranty period, Party B provides lifelong paid maintenance services for air conditioning users. Service content and mode, by the user and Party B separate voluntary contract to be determined.
Article VII due to the occurrence of force majeure factors resulting in the contract can not be normal fulfillment of the two sides to resolve the friendly negotiation.
Article VIII dispute resolution contract: the implementation of the contract dispute, the two sides to resolve friendly consultations. Consultation can not be resolved, either party may, in accordance with the law to the plaintiff's seat of the People's Court litigation.
Article IX of this contract shall enter into force on the date of signature and seal of both parties.
Article 10 submitted by Party B and confirmed by Party A of the project's design drawings and quotations program instructions and other documents
This is an annex to this contract.
Article 11 of this contract, if there are any other outstanding issues, the two sides **** with the consultation, to make additional provisions, additional provisions and this contract has the same effect.
Article 12 of the original contract in duplicate, A and B each party.
Article 13 of the contract annexes as part of the contract, and the contract has the same legal effect. Annexes to the contract:
Contractor (Party A): Contractor (Party B):
Address: Address:
Zip code: Zip code:
Representative: Representative:
Phone: Phone
Fax: Fax:
The contract shall be signed in two copies.