In a society where people's legal awareness is increasing, contracts are more and more widely used in life. Under normal circumstances, contracts must be signed in a prescribed way. There are different types of contracts, of course, they also have different purposes. The following are the model contracts (5 selected contracts) I collected for you. Welcome to share them. Reservoir construction contract 1

Party A:

Party B:

In accordance with the Contract Law of the People's Republic of China, the Construction Law of the People's Republic of China and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties have reached an agreement on this construction project.

1. General situation of the project:

Project name: fire pool;

project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

project area: the construction area of this project is * * * 1.99.5 square meters;

project cost: the total project cost is 521,111 yuan, in words: five hundred and twenty thousand yuan only.

ii. contract period:

this project started on October 11, 21 _ _ _, and was completed on October 26, 21____. The total number of calendar days is 16.

third, the contracting method:

the contracting method: take the form of contracting for work and materials.

IV. Quality standard

(1) Reinforced concrete is poured as a whole, the pool is 31 cm above the ground, and stainless steel railings are installed.

(2) The engineering quality standards shall be accepted according to the current national construction specifications;

(3) The project warranty shall be implemented in accordance with relevant regulations, and the warranty shall be calculated from the date of signing the completion acceptance;

V. Method of payment for the project

(1) Party B completes 51% of the engineering quantity, and Party A pays 31% of the total construction cost to Party B;

(2) Party A shall pay 91% of the total completion settlement price within seven days after the project is completed and accepted;

(3) The remaining 11% of the project payment shall be settled at one time within one year from the date of completion acceptance.

VI. Scope of responsibilities

(1) Responsibility of Party A:

1. Responsible for solving the problems of water and electricity use and smooth roads for construction;

2. Organize the project completion acceptance in time;

3. handle the completion inspection and acceptance within the time limit stipulated in this contract and pay party b the project payment.

(II) Party B's responsibilities:

1. Ensure the construction quality according to the construction safety standards, carefully construct, complete on time and deliver to use, and Party B shall be responsible for any construction quality and safety accidents during the construction period;

2. Party B has the obligation to repair the damage and deformation of the facilities adjacent to Party A during the construction;

3. Be responsible for cleaning up the construction waste in time, and after the construction, be responsible for cleaning up the construction waste in the site.

VII. Other matters

(1) Matters not covered in this contract shall be supplemented by both parties through research, which shall have the same legal effect as this contract.

(2) in case of any dispute during the execution of the contract, it shall be settled through friendly negotiation. If the negotiation fails, it may be submitted to the relevant arbitration institution for adjudication.

(3) this contract is made in duplicate, with each party holding 1 copies.

party a (seal): person in charge:

party b (seal): person in charge:

year month day reservoir construction contract 2

party a:

party b:

party a entrusts party b with the blasting design and construction of the stone works of the water pool in the capital construction site. The following agreements are reached through negotiation between both parties:

1. Project location:

2. Engineering quantity: about m3

3. Project cost: RMB

4. Payment method: Party B's equipment enters the site to start drilling operation, and Party A pays 51% of the project cost to Party B, and the remainder will be paid in one lump sum after the project is completed.

V. Responsibilities of Party A and Party B:

(1) Responsibilities of Party A:

1. Be responsible for removing the original turquoise and eluvial soil in the pool to facilitate Party B's drilling operation.

2. Send personnel to assist Party B in the blasting safety alert.

(2) Party B's responsibilities:

1. Responsible for handling the blasting construction procedures in relevant government departments.

2. Be responsible for the safety of the whole blasting process, and ensure that the blasting will not affect and destroy the structure of Party A's # residential building.

3. Operators should hold relevant certificates.

4. Strengthen the security alert.

VI. Liability for breach of contract:

1. Party B completes the blasting construction as required by Party A..

2. Party A shall settle the project payment on time, and shall not default on the project payment under any excuse.

VII. Matters not covered in this contract shall be settled by both parties through negotiation.

VIII. This contract is made in quadruplicate, with each party holding two copies.

Party A: Party B:

Party A's representative: Party B's representative: reservoir construction contract 3

Employer:

Contractor:

In accordance with the Contract Law of the People's Republic of China, the Construction Law of the People's Republic of China and the specific conditions of this project, the following agreement is reached:

1.

2. contract method and contract price

contract method: contracting for labor and materials, and fixed comprehensive unit price.

contract price: the total price is a comprehensive unit price of RMB 198,111 (in words: one hundred and ninety-eight thousand one hundred yuan only). The comprehensive unit price is fixed, and the quantities are settled according to the actual quantities recognized by the contractor and the employer. Repairing the ground, stamping the wall, iron gate, pump room equipment and underground pipeline are not included in the total price, and will be settled according to the actual engineering quantity after completion.

the comprehensive unit price is shown in the following table: Bill of Quantities Quotation Table

Bill of Quantities Quotation Table

3. Quality Requirements: Qualified

The technical standards and specifications quoted or involved in this contract shall be the latest and valid versions still in use in the People's Republic of China at the time of signing this contract.

4. Payment method:

Appropriation method: 21% of the contract price will be paid when the contractor's construction personnel and facilities enter the site; When 51% of the project construction is completed, 25% of the contract price shall be paid; Once the project is completed and accepted, it will be paid in one lump sum.

5. Duration:

5.1 Planned commencement date: 21__ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _: Planned completion date: year month day.

5.2 party b shall enter the site for construction according to the time required by party a .. Party B guarantees to complete the project on schedule. In case of the delay caused by Party A, on the day of the incident, Party B's on-site project manager will apply and the work will be postponed after being confirmed by Party A's on-site representative.

6. Inspection standard, method, place and time limit: Party A and Party B shall organize acceptance after the completion of the construction, and notify Party B in writing within three days after the completion of the acceptance. If Party B fails to receive the notification of acceptance result from Party A within three days after the acceptance, the project shall be deemed as qualified.

7. Work of both parties:

7.1 Work of Party A

7.1.1 Supervise and inspect the construction process of Party B..

7.1.2 organize relevant personnel to accept the project.

7.1.3 pay the project payment according to the contract.

7.1.4 provide water and power supply to ensure that the construction site is free from obstacles that hinder the smooth progress of the construction.

8.2 Work of Party B

8.2.1 Party B shall carry out the construction in strict accordance with Party A's requirements. Obey the command of Party A and the management.

be responsible for matters related to this project, project progress, technical quality, safe construction, inspection and acceptance, warranty and so on.

8.2.2 do a good job in site safety management according to the requirements of construction safety specifications, and set up site lighting and maintenance facilities as needed to prevent industrial accidents and ensure the safety of life and property of site personnel. If an accident occurs, it shall be handled actively and reported to Party A and relevant departments immediately, and the losses caused thereby shall be borne by Party B..

8.2.3 protect the finished products before the project is delivered.

9. Warranty period:

The warranty period is one year after the acceptance of this project.

11. Liability for breach of contract:

11.1 If Party A fails to perform its obligations as agreed in the contract, it shall compensate for the economic losses caused to Party B; If the construction is delayed due to Party A's responsibility, the construction period shall be postponed, and the expenses incurred due to the delay shall be borne by Party A..

11.2 party b's liability for breach of contract

if party b fails to complete the project within the time limit stipulated in the contract or fails to pass the acceptance, it shall bear the liability for breach of contract. If the construction is delayed due to Party B's reasons, the construction period will not be postponed.

11. treatment of breach of contract: if one party breaches the contract, the other party may propose to terminate or terminate the contract, and the breaching party shall bear corresponding responsibilities.

12. dispute settlement: in case of any dispute during the performance of the contract, both parties shall settle it through consultation in a timely manner based on the principle of fairness and reasonableness; if negotiation fails, they may apply to Shouguang Arbitration Commission for arbitration or bring a lawsuit to the people's court of the place where the contract is performed.

13. effectiveness and termination of the contract: this contract shall come into effect on the date of signature and seal by both parties. The contract price shall be terminated upon payment.

14. supplementary agreement: for matters not covered in this contract, both parties can sign a supplementary agreement, which has the same legal effect as this contract.

15. number of copies:

this contract is made in triplicate, one for each party and one for the manager.

party a:

party b:

year, month, day, reservoir construction contract 4

party a:

party b:

based on the principles of equality, mutual benefit, fairness and voluntariness, party a and party b have reached the following terms through friendly negotiation for their compliance.

1. General situation of the project

1. Project name: waterproofing in the clean water pool of Siyang Zhiying Thermal Power Plant and water leakage treatment in the coal conveying pit.

2. Project location: Siyang County Economic Development Zone.

3. Project content:

3.1(1) Wall sealing king, engineering glue, cement, hole sealing and priming.

(2) permeable cement-based crystal surface.

(3)JS-2 type twice.

3.2 the waterproof surface on the inner side of the clear water pool is * * * square meters, including the bottom, east, west, south and north.

3.3 The water leakage and waterproof treatment fee for coal pit is 611 yuan.

4. The unit price of clear water pool waterproofing in this contract project is 31 yuan/m2, and the cost of clear water pool waterproofing project is RMB (in words), so the price adjustment is not required.

5. The total project cost of this contract is RMB (in words) (including tax)

2. Quality requirements and acceptance criteria

(1) It meets the GB51218-2122 Code for Quality Acceptance of Underground Waterproofing Engineering

(2) Full water test, and the pool is filled with water for 72 hours without water leakage.

III. Requirements for the construction period

Waterproofing of clean water tank: February 2, 21____—February 7, 21 _ _ _ (completion); Water leakage treatment of coal bunker: February 8, 21xx-February 9, 21xx (completion)

IV. Payment method (bank transfer) <

party a: party b: (signature) (seal) id number: authorized representative:

date: bank of deposit: account number: date: reservoir construction contract 5

party a:

party b:

according to the contract law of the people's Republic of China, the contract law of the people's Republic of China and the state construction.

2. contract method and contract price

contract method: lump sum price (including tax).

contract price: the total price is RMB (in words: ten thousand yuan only).

3. Quality requirements

Construction shall be carried out according to the design drawings provided by Party A, reaching the national acceptance standard. The technical standards and specifications quoted or involved in this contract are the latest and effective versions still in use in the People's Republic of China when this contract is signed.

4. payment method: 95% of the total price will be paid after the project is completed, and 5% of the quality guarantee will be paid after one year.

5. The construction period is

5.1 calendar days.

5.2 party b shall enter the site for construction according to the time required by party a .. Party B guarantees to complete the project on schedule. In case of delay caused by Party A, on the day of the incident, Party B's on-site project manager will apply for it, and the construction period will be extended after it is confirmed by Party A's on-site representative.

6. Inspection standard, method, place and time limit

After the construction of the fire pool is completed, Party A and Party B shall organize the acceptance according to the relevant national standards. For those that do not meet the specifications and design requirements, Party A shall notify Party B in writing to rework within three days after the acceptance. If Party B fails to receive the notification of acceptance result from Party A within three days after the acceptance, the project shall be deemed as qualified.

7. Work of both parties

7.1 Work of Party A

7.1.1 Supervise and manage the construction process of Party B..

7.1.2 organize relevant personnel to accept the project.

7.1.3 pay the project payment according to the contract.

7.1.4 provide water and power (expenses shall be borne by party b).

7.2 Work of Party B

7.2.1 Party B shall carry out the construction in strict accordance with the drawings and design requirements provided by Party A and obey the supervision. Be responsible for matters related to the progress, technical quality, safe construction, inspection and acceptance, supervision data inspection, warranty and so on.

7.2.2 do a good job in site safety management according to the requirements of construction safety specifications to ensure the safety of site personnel and property. If a safety accident occurs, it shall be handled actively and immediately reported to Party A and relevant departments, and all responsibilities and losses caused thereby shall be borne.

7.2.3 protect the finished products before the project is delivered.

8. Liability for breach of contract

8.1 If Party A fails to perform its obligations as agreed in the contract, thus causing economic losses to Party B, it shall compensate 5% of the total contract price as liquidated damages; If the construction is delayed due to Party A's responsibility, the construction period shall be postponed, and the expenses incurred due to the delay shall be borne by Party A..

8.2 if party b fails to complete the project within the time limit stipulated in the contract or fails to pass the acceptance, it shall bear the liability for breach of contract and compensate party a for 5% of the total contract price. If the construction is delayed due to Party B's reasons, the construction period will not be postponed, and the corresponding economic losses will be borne.

9. dispute settlement

in case of any dispute during the performance of the contract, both parties shall settle it through consultation in a timely manner based on the principle of fairness and reasonableness; if negotiation fails, they may bring a lawsuit to the people's court of the place where the contract is performed.

12. supplementary provisions

this contract shall come into force as of the date of signature and seal by both parties. The contract price shall be terminated upon payment.